Southland Holdings, Inc._December 31, 2024
Table of Contents
UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
Form 10-K
For the fiscal year ended December 31, 2024
OR
☐ TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
For the transition period from to .
Commission File Number: 001-41090
Southland Holdings, Inc.
(Exact name of registrant as specified in its charter)
(State or other jurisdiction of (I.R.S. Employer
incorporation or organization) Identification No.)
1100 Kubota Dr.
Grapevine, TX76051
(Address of principal executive offices) (Zip Code)
(817) 293 - 4263
(Registrant’s telephone number, including area code)
Securities registered pursuant to Section 12(b) of the Act:
Title of each class Trading Symbol(s) Name of each exchange on which registered
Common stock, par value $0.0001 per share SLND NYSE American LLC
Securities registered pursuant to Section 12(g) of the Act: None
Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes ☐ No☒
Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or 15(d) of the Exchange Act. Yes ☐No☒
Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes☒No ☐
Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T (section 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit such files).
Yes☒No ☐
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company or an emerging growth company. See the definitions of “large accelerated filer”, “accelerated filer”, “smaller reporting company” and “emerging growth company” in Rule 12b-2 of the Exchange Act.
Large accelerated filer ☐ Accelerated filer ☐
Non-accelerated filer ☒ Smaller reporting company ☒
Emerging growth company ☒
If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act☐
Table of Contents
Indicate by check mark whether the registrant has filed a report on and attestation to its management’s assessment of the effectiveness of its internal control over financial reporting under Section 404(b) of the Sarbanes-Oxley Act (15 U.S.C. 7262(b)) by the registered public accounting firm that prepared or issued its audit report. ☐
If securities are registered pursuant to Section 12(b) of the Act, indicate by check mark whether the financial statements of the registrant included in the filing reflect the correction of an error to previously issued financial statements. ☐
Indicate by check mark whether any of those error corrections are restatements that required a recovery analysis of incentive-based compensation received by any of the registrant’s executive officers during the relevant recovery period pursuant to §240.10D-1(b). ☐
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).☐Yes☒No
As of February 24, 2025, 53,987,069 shares of common stock, par value $0.0001 per share, were issued and outstanding. The aggregate market value of the common stock held by non-affiliates of the registrant was approximately $57,451,112 as of June 30, 2024, the last business day of the registrant’s most recently completed second fiscal quarter, based on the last sales price of the registrant’s common stock as reported on the NYSE American LLC on such date. For purposes of the preceding sentence only, all directors, executive officers and beneficial owners of 10% or more of the shares of the registrant’s common stock are assumed to be affiliates.
Documents Incorporated by Reference:
Items 10, 11, 12, 13, and 14 of Part III incorporate information by reference from the registrant’s definitive proxy statement relating to its 2025 annual meeting of stockholders (the “2025 Proxy Statement”) to be filed with the Securities and Exchange Commission no later than 120 days after the close of the registrant’s fiscal year to which this report relates.
Table of Contents
TABLE OF CONTENTS
Page
PART I 3
Item 1. Business 3
Item 1A. Risk Factors 10
Item 1B. Unresolved Staff Comments 30
Item 1C. Cybersecurity 30
Item 2. Properties 31
Item 3. Legal Proceedings 31
Item 4. Mine Safety Disclosures 31
PART II 32
Item 6. Reserved 32
Item 7A. Quantitative and Qualitative Disclosures about Market Risk 44
Item 8. Financial Statements and Supplementary Data 44
Item 9A. Controls and Procedures 44
Item 9B. Other Information 45
PART III
Item 10. Directors, Executive Officers and Corporate Governance 46
Item 11. Executive Compensation 46
Item 14. Principal Accountant Fees and Services 46
PART IV
Item 15. Exhibits and Financial Statement Schedules 47
Item 16. Form 10-K Summary 49
Index to Consolidated Financial Statements F-1
i
Table of Contents
Unless otherwise stated in this Annual Report on Form 10-K (this “Annual Report”), references to the “Company,” “our,” “us,” “we,” or “Southland” refer to Southland Holdings, Inc. and its consolidated subsidiaries.
CAUTIONARY NOTE REGARDING FORWARD-LOOKING STATEMENTS
This Annual Report includes forward-looking statements within the meaning of Section 27A of the Securities Act of 1933 (the “Securities Act”), as amended, and Section 21E of the Securities Exchange Act of 1934, as amended (the “Exchange Act”). These statements are based on the reasonable beliefs and assumptions of our management. Forward-looking statements are inherently subject to risks, uncertainties and assumptions. Generally, statements that are not historical facts, including statements concerning possible or assumed future actions, business strategies, events or results of operations, are forward-looking statements. These statements may be preceded by, followed by or include the words “believes,” “estimates,” “expects,” “projects,” “forecasts,” “may,” “will,” “should,” “seeks,” “plans,” “scheduled,” “anticipates,” “intends” or similar expressions. Forward-looking statements contained in this Annual Report include, but are not limited to, statements about our ability to:
● Access, collect and use personal data about consumers;
● Retain and hire necessary employees;
● Increase brand awareness;
● Attract, train and retain effective officers, key employees or directors;
● Upgrade and maintain information technology systems;
● Acquire, develop and protect intellectual property;
● Obtain additional capital, including use of debt and capital markets;
● Achieve or enhance future operating and financial results;
● Anticipate rapid technological changes;
● Stay abreast of modified or new laws and regulations applying to our business;
● Anticipate the impact of, and respond to, new accounting standards;
● Anticipate the significance and timing of contractual obligations;
● Manage to finance operations on an economically viable basis;
● Successfully defend, pursue or collect claims and litigation; and
Forward-looking statements are not guarantees of performance and speak only as of the date hereof. While we believe that these forward-looking statements are reasonable, there can be no assurance that we will achieve or realize these plans, intentions, or expectations. You should understand that the following important factors, in addition to those discussed under the heading “Item 1A. Risk Factors” and elsewhere in this Annual Report, could affect our future results
1
Table of Contents
and could cause those results or other outcomes to differ materially from those expressed or implied in the forward-looking statements in this Annual Report:
● Litigation, complaints, product liability claims and/or adverse publicity;
● Privacy and data protection laws, privacy or data breaches or the loss of data
These and other factors that could cause actual results to differ from those implied by the forward-looking statements in this Annual Report are more fully described under the heading “Item 1A. Risk Factors” and elsewhere in this Annual Report. The risks described under the heading “Item 1A. Risk Factors” are not exhaustive. Other sections of this Annual Report may describe additional factors that could adversely affect our business, financial condition or results of operations. New risk factors emerge from time to time and it is not possible to predict all such risk factors, nor can we assess the impact of all such risk factors on the business, nor the extent to which any factor or combination of facts may cause actual results to differ materially from those contained in any forward-looking statements. All forward-looking statements attributable to us or persons acting on our behalf are expressly qualified in their entirety by the foregoing cautionary statements. We undertake no obligations to update or revise publicly any forward-looking statements, whether as a result of new information, future events or otherwise, except as required by law.
In addition, statements of belief and similar statements reflect our reasonable beliefs and opinions on the relevant subject. These statements are based upon information available to us, as applicable, as of the date of this Annual Report, and while we believe such information forms a reasonable basis for such statements, such information may be limited or incomplete, and such statements should not be read to indicate that we have conducted an exhaustive inquiry into, or review of, all potentially available relevant information. These statements are inherently uncertain, involve risks and are subject to change based on various factors, including those discussed under the headings “Item 1A. Risk Factors” and “Item 7. Management Discussion and Analysis” in this Annual Report.
BASIS OF PRESENTATION
On May 25, 2022, Legato Merger Corp. II, a Delaware corporation (“Legato II” and, after the Merger as described below “Southland”), entered into an Agreement and Plan of Merger (the “Merger Agreement”) with Legato Merger Sub Inc., a Delaware corporation and wholly owned subsidiary of Legato II (“Merger Sub”), and Southland Holdings LLC, a Texas limited liability company (“Southland LLC”).
On February 14, 2023 (the “Closing Date”), as contemplated by the Merger Agreement, Merger Sub merged with and into Southland LLC, with Southland LLC surviving the merger as a wholly owned subsidiary of Legato II (the “Merger”). The transactions contemplated by the Merger Agreement are referred to herein collectively as the “Business Combination.” In connection with the Business Combination, Legato II changed its name to “Southland Holdings, Inc.”
The Merger was accounted for as a reverse recapitalization with Southland LLC as the accounting acquirer and Legato II as the acquired company for accounting purposes. Accordingly, all historical financial information presented in the consolidated financial statements represents the accounts of Southland and its subsidiaries as if Southland had been the predecessor Company. The structure of Southland’s historical common equity structure was in the form of membership percentages and no shares were issued. As such, reporting periods prior to the three months ended March 31, 2023, will not present share or per share data.
Holders of 25,193,748 shares of Legato II common stock elected to have their shares redeemed in connection with the Business Combination. At the closing of the Business Combination, the Company issued 33,793,111 shares of common stock to the former members of Southland (“Southland Members”) in exchange for their membership interests in Southland (“Southland Membership Interests”).
Our common stock, par value $0.0001 per share (“Common Stock”), and redeemable warrants, exercisable for shares of Common Stock at an exercise price of $11.50 per share (“Warrants”), trade on NYSE under the symbols “SLND” and “SLND WS,” respectively.
2
Table of Contents
Part I
Item 1. Business
Overview
Southland is a diverse leader in specialty infrastructure construction with roots dating back to 1900. The end markets for which we provide services cover a broad spectrum of specialty services within infrastructure construction. We design and construct projects in the bridges, tunnels, communications, transportation and facilities, marine, steel structures, water and wastewater treatment, and water pipelines end markets.
Southland is based in Grapevine, Texas. It is the parent company of Johnson Bros. Corporation, American Bridge Company, Oscar Renda Contracting, Southland Contracting, Mole Constructors, and Heritage Materials. With the combined capabilities of these six primary subsidiaries, Southland has become a diversified industry leader with projects spanning North America in various end markets.
In the second quarter of 2023, Southland decided to discontinue certain types of projects in its Materials & Paving business line (“M&P”) and sold assets related to producing large scale concrete and asphalt. M&P is reported in the Transportation segment. The Company will not be pursuing production of concrete and asphalt products for use on self-performed paving projects where the majority of the scope of work contains large-scale concrete and asphalt production or sale of asphalt and concrete products to third parties. This operational shift will allow the Company to better focus its resources on more profitable lines of business.
Reportable Segments
We manage Southland in two distinct segments: Civil and Transportation.
Our Civil segment operates throughout North America and specializes primarily in services that include the design and construction of water pipeline, pump stations, lift stations, water and wastewater treatment plants, concrete and structural steel, outfall, and tunneling.
Our Transportation segment operates primarily throughout North America and specializes primarily in services that include the design and construction of bridges, roadways, marine, dredging, ship terminals and piers, and specialty structures and facilities. Our Transportation segment is responsible for the construction of bridges and structures throughout North America, and other parts of the world, including many of the most recognizable bridges, convention centers, sports stadiums, marine facilities, and Ferris wheels in the world.
Customers
Our customers are a mixture of public and private entities. Our public sector includes certain federal agencies, state departments of transportation, local transit authorities, county and city public works departments, and utilities, while our private customers consist largely of the owners of industrial, commercial, and residential sites. The majority of both our public and private customers are located in the United States; however, we have large projects in Canada and the Bahamas, and experience in worldwide markets.
Management within each of our business segments is responsible for cultivating and maintaining successful long-term relationships with customers. Our local and corporate management teams build relationships with current and potential customers in order to better understand and serve their needs which benefits us in the competitive bid process.
We believe that our strategic relationships with customers will result in future opportunities. While relationships are important, we realize that future opportunities also require cost effective bids, as pricing is a key element for most construction projects.
3
Table of Contents
Strategy
Southland exists to build great things that shape our landscape and foster reliable infrastructure for future generations. Across our regional base of offices, Southland provides both Civil and Transportation infrastructure projects to a diverse base of public and private clients. These clients benefit from our market intelligence, local relationships, and our expert knowledge of design and construction.
Seasonal, Cyclicality, and Variability
The results of our operations are subject to quarterly variations. Much of the variation is the result of weather, particularly heat, wind, snow, ice, rain and named storms, which can impact our ability to perform construction activities. These weather impacts can affect revenue and profitability in either of our business segments. Any quarter can be affected either negatively or positively by atypical weather patterns in any part of North America, or other areas in which we operate. Traditionally, our first quarter is the most weather-affected; however, this may not necessarily be true in future periods. Our ability to negotiate change orders for the impact of weather on a project could impact our profitability. In addition, the impact of weather can cause significant variability in our quarterly revenue and profitability.
Our business may also be affected by overall economic market declines, delays in new projects, changes in client schedules, or for other reasons.
4
Table of Contents
Competition and Market Trends
In both our Transportation and Civil segments, we have competitors within the individual markets and geographic areas in which we operate, ranging from small, local companies to larger regional, national, and international companies. Although the construction business is highly competitive, there are few, if any, companies which compete in all of our market areas, both geographically and from an end market perspective. The degree and type of competition is influenced by the type and scope of construction projects within individual markets. Equipment ownership and ability to self-perform across numerous disciplines are two of our significant competitive advantages. We believe that the primary factors influencing competition in our industry are price, reputation for quality, safety, schedule certainty, relevant experience, availability of field supervision and skilled labor, machinery and equipment, financial strength, as well as knowledge of local markets and conditions.
Many of our competitors have the ability to perform work in either the private or public sectors. When opportunities for work in one sector are reduced, competitors tend to look for opportunities in the other sector. This migration has the potential to reduce revenue growth and/or increase pressure on gross profit margins.
We believe that the combination of our experience, reputation, and technical expertise are unmatched among companies of our size. This combination of skills has allowed us to pursue large-scale projects with fewer competitors.
Contract Provisions and Subcontracting
Our contracts are primarily obtained through competitive bidding. Occasionally, we obtain contracts through direct negotiations with customers. We are often invited to bid on projects with customers who maintain pre-qualified contractor lists. Contractors are often selected for pre-approved contractor lists by virtue of their prior performance for such customers, as well as their reputation, technical expertise, safety record, ability to obtain surety bonds, experience, and other factors.
When considering bid opportunities, we evaluate factors such as the customer, the geographic location of the work, the availability of labor, our competitive advantage or disadvantage relative to other bidders, our current and projected workload, the likelihood of additional work, our history with the client, contract terms, the project’s cost and profitability estimates, and other factors. We have an experienced estimating staff using sophisticated estimating systems. The project estimates form the basis of a project budget against which performance is tracked through a project cost system, thereby enabling management to monitor a project’s cost and schedule performance. Project costs are accumulated and monitored regularly against billings and payments to ensure proper tracking of cash flow on the project.
Most of our contracts allow for termination by either us or our customer. The terms of these contracts typically cover the reimbursement of our costs through a specified date, along with additional reimbursement for demobilizing our employees and equipment from the project site. Some contracts are subject to completion schedule requirements which can include liquidated damages in the event schedules are not met.
We serve as the prime contractor on the majority of our projects. In the construction industry, the prime contractor is responsible for the execution of the entire contract scope of work, including subcontract work. As prime contractor, we are responsible for work of our subcontractors, and we are potentially subject to increased costs and reputational risks associated with the failure of one or more of our subcontractors to perform their respective scope as defined in the contract. While we may subcontract specialized activities such as blasting, hazardous waste removal and selected electrical/instrumentation work, we seek to self-perform most of the work on our projects with our own resources, including field supervision, labor, and equipment.
Contract Backlog
Contract backlog (“Backlog”) in our industry is an economic measure of the total value of work remaining to be earned on projects that have been awarded. Backlog consists of two components: (1) unearned revenue and (2) contracts awarded but not started. Unearned revenue includes the revenue we expect to record in the future on in-progress contracts, including 100% of our consolidated joint venture contracts and our proportionate share of unconsolidated joint venture
5
Table of Contents
contracts. Contracts that are awarded, but not yet started, are included in Backlog once a contract has been fully executed and/or we have received a formal “Notice to Proceed” from the project owner.
Although contract backlog reflects business that we consider to be firm, deferrals, cancellations, or scope adjustments may occur. Backlog is adjusted to reflect any known project cancellations, revisions to project scope and projected revenues, foreign currency exchange fluctuations, and project deferrals, as appropriate.
Fixed price contracts, particularly with federal, state, and local government customers, are expected to continue to represent a majority of our total Backlog.
(Amounts in thousands)
New contracts, change orders, and adjustments 1,011,797
New contracts, change orders, and adjustments 718,125
Less: contract revenue recognized in 2024 (980,179)
Construction Costs and Raw Materials
We manage our business to minimize exposure to labor and material price increases, including through inflation or other factors, in our bids for projects, when possible. Our contracts may contain protections in the case of excessive increases in the cost of either labor or equipment. In our fixed price contracts, we bid with assumptions of increases in wages and prices of raw materials. Frequently, we obtain fixed price quotes from major subcontractors and material suppliers early in our project schedules. Our fixed price contract bids also tend to contain contingencies for inflation or other significant increases. The construction supplies and other materials needed to complete our projects are often available from multiple suppliers which insulates us from being overly reliant on any particular vendor, however this is not always the case.
Supply-chain disruption has continued for many of the materials and inputs that we need to complete our projects. Specifically, prices of oil, gas, and other fuel sources have increased over time since certain projects were originally estimated. Additionally, the cost and availability of many construction materials and labor has impacted project costs and scheduling. Changes in laws, policies or regulations, including tariffs and taxes, could impact the prices for materials or equipment. We have continued to mitigate these impacts to the extent possible by passing these costs on to our customers when possible and agreeing to fixed-cost contracts with suppliers and subcontractors for labor and materials.
Our operations can be impacted by increases in prices, whether caused by inflation or other factors. We attempt to recover anticipated increases in the cost of labor, materials, equipment, and fuel through price escalation provisions in certain contracts and by considering the estimated increases in costs in our bidding on new work. We often seek to get fixed-price bids from subcontractors and suppliers upon signing new contracts to control costs. However, our industry has continued to face material impacts to profitability due to increased costs. We may incur increased project costs due to increased prices in the future.
Since the novel coronavirus (“COVID-19”) pandemic and Russia’s invasion of Ukraine, the construction industry continues to experience widespread supply chain impacts. Labor costs continue to increase due to inflation, shortages of qualified workers, and other factors. Hiring and retaining our skilled workers continues to be a priority to avoid future potential labor shortages.
Risk Management, Insurance, and Bonding
We are insured to cover a broad range of exposures arising from our work in the construction industry. All of our policies have been procured with limits and deductibles or self-insured retention amounts of varying amounts per occurrence. We believe that our insurance coverage meets or exceeds our needs relating to casualty or other type of insurance loss.
6
Table of Contents
Our safety team has created an atmosphere of safety at our projects. Our safety directors and site-specific safety managers work together to assess and control potential losses and liabilities both before and during our construction projects. Our safety record is in-line with industry standards.
In our industry, we are generally required to possess various types of surety bonds guaranteeing our completion of projects for most public and private customer contracts. Surety bond costs and our ability to obtain surety bonds are largely contingent on our working capital, Backlog, past performance and reputation, capitalization, management and technical expertise, and other factors at the underwriter’s discretion. Historically, we have been able to acquire the level of surety bonds necessary to support our business, but there can be no assurances that we can secure all necessary or appropriate surety bonds in the future or that such surety bonds can be economically secured. See “Item 1A. Risk Factors” for further discussion of related risks.
Government Regulations
Our business is subject to environmental, health and safety, government procurement, anti-bribery, and other government regulations and requirements. We believe that we have all of the necessary licenses required to conduct our operations and that we are in substantial compliance with applicable regulatory requirements.
Below is a summary of some of the significant regulations that impact our business.
Environmental
Our operations are subject to various federal, state, local, and foreign laws and regulations relating to the environment, including those relating to the Clean Water and Clean Air Acts. In addition, the Environmental Protection Agency (the “EPA”) and other federal, state, local, and international agencies regulate our operations in regards to the handling, transportation and disposal of non-hazardous and hazardous substances and waste, as well as emission and discharges into the environment; including discharges to air, surface water, groundwater, soil, and others.
We have a substantial investment in construction equipment that utilize diesel and gasoline fuel, which could be negatively impacted by regulations related to greenhouse gas emissions from such sources.
We are subject to laws and regulations governing the liability and cleanup responsibility for the release of hazardous substances into the environment. Under certain of these laws and regulations, liability can be assessed for sites to which hazardous substances or wastes were sent by current, or former operations at our facilities, or for the cleanup of previously owned or leased properties, irrespective of whether our activities were in violation of laws and regulations at the time or whether we directly caused the contamination. The presence of contamination from hazardous substances or wastes at our sites could preclude the sale, lease or use of our properties as collateral for financing.
We evaluate our compliance with environmental laws on a continual basis.
The majority of our revenue was recognized from contracts funded by federal, state, and local government agencies and authorities. Government contracts contain specific procurement regulations, contract provisions, and a variety of other requirements related to formation, administration, project performance, and accounting. These agreements often require certification of compliance.
Our operations are subject to various statutes and executive orders. These include but are not limited to:
● the Davis-Bacon Act which regulates wages and benefits,
7
Table of Contents
● the Drug-Free Workplace Act, and
● the Federal Acquisition Regulation and the Federal Civil False Claims Act.
We are also subject to the rules and regulations promulgated by the Occupational Safety and Health Administration (“OSHA”) and the Mine Safety and Health Administration and other regulations. In addition, certain contracts contain minimum Disadvantaged Business Enterprise (“DBE”) participation clauses.
These laws and regulations affect how we transact business and, in some instances, impose additional costs on our business operations, which may adversely affect our business, results of operations and financial condition. As further described in “Item 1A. Risk Factors,” violation of specific laws and regulations could lead to fines, contract termination, debarment of contractors and/or suspension of future contracts. Our government customers can also terminate, renegotiate or modify any of their contracts with us at their convenience.
Anti-Corruption and Bribery
We are subject to the Foreign Corrupt Practices Act (“FCPA”). The FCPA prohibits U.S. and other business entities from making improper payments to foreign government officials, political parties or political party officials. We are also subject to the applicable anti-corruption laws in the jurisdictions in which we operate, thus potentially exposing us to liability and potential penalties in multiple jurisdictions. The anti-corruption provisions of the FCPA are enforced by the Department of Justice while other state or federal agencies may seek recourse against the Company for issues related to FCPA. In addition, the Securities and Exchange Commission (“SEC”) requires strict compliance with certain accounting and internal control standards set forth under the FCPA. Failure to comply with the FCPA and other laws can expose us and/or individual employees to potentially severe criminal and civil penalties. Such penalties may have a material adverse effect on our business, results of operations and financial condition. We devote resources to the development, maintenance, communication and enforcement of our Code of Business Conduct, our anti-bribery compliance policies, our internal control processes and compliance related policies. We strive to conduct timely internal investigations of potential violations and take appropriate action depending upon the outcome of the investigation.
Human Capital Resources
We have built a culture of hard work and excellence with a diverse and inclusive workplace as a business imperative because our people are our single most important asset. In our high-performance culture, everyone is treated fairly and respectfully and has equal access to opportunities based on capabilities and performance, regardless of gender, generation, sexual orientation, mental and physical ability, race, ethnicity, and other protected classes.
Our workforce was made up of approximately 2,100 employees as of December 31, 2024, of which approximately 500 were salaried and approximately 1,600 were hourly.
Union Workforce.
Several of our subsidiaries are signatory to numerous local and regional collective bargaining agreements, both directly and through trade associations, as a union contractor. These agreements cover all necessary union professions and are subject to renewal periodically. As of December 31, 2024, approximately 300, or 14%, of our employees were represented by a union. Estimated amounts for wage escalation related to the expiration of union contracts are included in our bids on various projects.
Diversity and Inclusion
We employ a dynamic mix of people to create the strongest company possible. Our policy strictly forbids discrimination in employment on the basis of age, culture, gender, national origin, sexual orientation, physical appearance, race, or religion. We are an inclusive, diverse company with people of all backgrounds, experience, culture, styles, talents, and other protected classes.
8
Table of Contents
Professional and Career Development
We strive to develop and sustain a skilled labor advantage by providing thorough on and off-site training programs, project management training, and leadership development programs.
Safety, Health, and Wellness
We are committed to providing a safe environment for our employees. We pride ourselves in our above industry average workplace safety. We track and maintain several key safety metrics, which senior management reviews monthly, and we evaluate management on their ability to provide safe working conditions on job sites and to create a strong safety culture.
Compensation and Benefits
As part of our compensation philosophy, we believe that we must offer and maintain market competitive total compensation and benefit packages for our employees in order to attract and retain superior talent. We benchmark our benefits package against our competitors on a yearly basis.
We also may provide additional benefits to our employees, including a 401(k) match plan, healthcare and insurance benefits, paid time off, family leave, flexible work schedules, and employee assistance programs.
Code of Business Conduct
All of our employees are subject to our Code of Business Conduct, which includes guidance and requirements concerning, among other things, general business ethics, including policies concerning the environment, conflicts of interest, anti-corruption, harassment and discrimination, data security and privacy, and the Anti-Bribery and Corruption Policy, which includes guidance and requirements concerning, among other things, interactions with government officials; provisions of gifts, entertainment and hospitality, and charitable and political contributions.
Company History and Available Information
The Company was incorporated in on July 14, 2021 as a Delaware corporation for the purpose of entering into a merger, share exchange, asset acquisition, stock purchase, recapitalization, reorganization or other similar business combination with one or more businesses or entities. On February 14, 2023, the Company consummated the merger contemplated by the Merger Agreement, dated as of May 25, 2022 (the “Merger Agreement”), by and among Southland Holdings, Inc. (known prior to February 14, 2023 as Legato Merger Corp. II), Southland Holdings LLC, a Texas limited liability company, and Legato Merger Sub, Inc., a Delaware corporation. Upon the closing of the transactions contemplated in the Merger Agreement, we changed our name to Southland Holdings, Inc.
Our principal executive offices are located at 1100 Kubota Dr., Grapevine, Texas 76051, and our telephone number is (817) 293-4263. Our Internet address is www.southlandholdings.com. We are not including the information contained in our website as part of, or incorporating it by reference into, this Annual Report on Form 10-K. We make available free of charge through our website our Annual Reports on Form 10-K, Quarterly Reports on Form 10-Q, Current Reports on Form 8-K and amendments to these reports filed or furnished pursuant to Section 13(a) or 15(d) of the Exchange Act as soon as reasonably practicable after we electronically file such materials with, or furnish it to, the SEC. We also make available on our website the charters for our Audit Committee, Nominating and Corporate Governance Committee and Compensation Committee and our Code of Business Conduct, which applies to all of our employees, including our executive officers. All such information is also available in print and free of charge to any of our stockholders who request it. In addition, we intend to disclose on our website any amendments to, or waivers from, our Code of Business Conduct that are required to be publicly disclosed pursuant to rules of the SEC. Additionally, all of our reports filed with the SEC are available via their website at sec.gov.
9
Table of Contents
Item 1A. Risk Factors
Risk Factor Summary
We are providing the following summary of the risk factors disclosed in this Annual Report to enhance the readability and accessibility of our risk factor disclosures. We encourage our stockholders to carefully review the risk factors disclosed in this Annual Report in their entirety for additional information regarding the material factors that make an investment in our securities speculative or risky.
Risks Related to Our Business and Industry
● We may lose business to competitors through competitive bidding processes.
● Our Backlog is subject to unexpected adjustments and cancellations.
● The loss of one or more customers could have an adverse effect on us.
● Some of our contracts have penalties for late completion.
10
Table of Contents
Risks Related to our Securities
● An established market for our securities may not be sustained.
11
Table of Contents
Risks Relating to Southland’s Business and Industry
We may lose business to competitors through competitive bidding processes.
We are engaged in highly competitive businesses in which most customer contracts are awarded through bidding processes based on price and the acceptance of certain risks, along with other factors. We compete with other general and specialty contractors, regional, national and international, as well as small local contractors. The strong competition in our markets requires maintaining skilled personnel and investing in technology and also puts pressure on profit margins. Some of our competitors may have greater resources which may result in a decrease in new awards, a decrease in profit margins, or both. We do not obtain contracts from all of our bids and our inability to win bids at acceptable profit margins could adversely affect our business.
Our Backlog is subject to unexpected adjustments and cancellations.
Our Backlog generally consists of projects for which we have an executed contract or commitment with a customer and reflects our expected revenue from the contract or commitment, which is often subject to revision over time. We cannot guarantee that the revenue projected in our Backlog will be realized or profitable or will not be subject to delay or suspension. Project cancellations, scope adjustments or deferrals or foreign currency fluctuations may occur with respect to contracts reflected in our Backlog, which could reduce the dollar amount of our Backlog and the revenue and profits that we actually earn or cause the rate at which we perform on our Backlog to decrease. In addition, projects may remain in our Backlog for an extended period of time. During periods of economic slowdown, the risk of projects being suspended, delayed or canceled generally increases. Finally, poor project or contract performance could also impact our Backlog and profits. Such developments could have a material adverse effect on our business and our profits.
The loss of one or more customers could have an adverse effect on us.
A few customers, including the federal, state and local governments and governmental agencies, comprise a significant portion of our revenue. Our customers may unilaterally reduce, fail to renew, terminate their contracts with us, or revoke our ability to submit bids on new work at any time. Some of our contracts may have “termination for convenience” provisions in them. In addition, a significant reduction in government spending or a change in budgetary priorities could reduce demand for our services, cancel or delay projects. The loss of business from a significant customer could have a material adverse effect on our business, financial position and results of operations.
We are subject to risks related to government contracts and related procurement regulations.
Our contracts with federal, state, local and foreign government entities and agencies are subject to various procurement regulations and other requirements relating to their formation, administration and performance. Government contracts expose us to a variety of risks that differ from those associated with private sector contracts. Various statutes to which our operations are subject, including, among others, the Davis-Bacon Act (which regulates wages and benefits), the Walsh-Healy Act (which prescribes a minimum wage and regulates overtime and working conditions), Executive Order 11246 (which establishes equal employment opportunity and affirmative action requirements) and the Drug-Free Workplace Act, provide for mandatory suspension and/or debarment of contractors in certain circumstances involving statutory violations. In addition, the Federal Acquisition Regulation and various state statutes provide for discretionary suspension and/or debarment in certain circumstances that might call into question a contractor’s willingness or ability to act responsibly, including as a result of being convicted of, or being found civilly liable for, fraud or a criminal offense in connection with obtaining, attempting to obtain or performing a public contract or subcontract. The scope and duration of any suspension or debarment may vary depending upon the facts and the statutory or regulatory grounds for debarment and could have a material adverse effect on our financial position, results of operations, cash flows and liquidity.
Government contracts are subject to specific procurement regulations, contract provisions and a variety of socioeconomic requirements relating to their formation, administration, performance and accounting and often include express or implied certifications of compliance. Claims for civil or criminal fraud may be brought for violations of regulations, requirements or statutes. We may also be subject to qui tam litigation brought by private individuals on behalf of the government under the Federal Civil False Claims Act, which could include claims for up to treble damages. Further,
12
Table of Contents
if we fail to comply with any of the regulations, requirements or statutes or if we have a substantial number of accumulated Occupational Safety and Health Administration, Mine Safety and Health Administration or other workplace safety violations, our existing government contracts could be terminated and we could be suspended from government contracting or subcontracting, including federally funded projects at the state level. Should one or more of these events occur, it could have a material adverse effect on our financial position, results of operations, cash flows and liquidity.
The timing of new contract starts, including delays, cancellations and scope alternations, may result in unpredictable fluctuations in our business.
Substantial portions of our revenue are derived from project-based work that is awarded through a competitive bid process. It is generally very difficult to predict the timing and geographic distribution of the projects that we will be awarded. The selection of, timing of or failure to obtain projects, delays in award of projects, the re-bidding or termination of projects due to budget overruns, cancellations of projects or delays in completion of contracts could result in the under-utilization of our assets and reduce our cash flows. Even if we are awarded contracts, we face additional risks that could affect whether, or when, work will begin. For example, some of our contracts are subject to financing, permitting and other contingencies that may delay or result in termination of projects. We may have difficulty in matching workforce size and equipment location with contract needs. In some cases, we may be required to bear the cost of a ready workforce and equipment that is larger than necessary, resulting in unpredictability in our cash flow, expenses and profitability. If any expected contract award, or the related work release is delayed or not received, we could incur substantial costs without guaranteed receipt of any corresponding revenue. Finally, the winding down or completion of work on significant projects could reduce our revenue and earnings if these projects have not been replaced.
We are vulnerable to the cyclical nature of the markets we serve.
The demand for our services is dependent upon the existence of projects with construction needs. Our customers’ interest in approving new projects, budgets for capital expenditures and need for our services may be adversely affected by, among other things, poor economic conditions, including an economic recession, low oil prices, political uncertainties and currency devaluations. Customers may be selective in how they allocate and expend their capital, which could result in a reduction of the number of projects we may bid on and win. Many of the industries that we serve are vulnerable to general downturns, which in turn could materially and adversely affect the demand for our services.
Demand for our services may increase or decrease during economic recessions or volatile economic cycles, and a reduction in demand in end markets may adversely affect our business.
A substantial portion of our revenue and profit is generated from construction projects, the awarding of which we do not directly control. The engineering and construction industry has historically experienced cyclical fluctuations in financial results due to economic recessions, downturns in business cycles of our customers, material shortages, price increases by subcontractors, interest rate fluctuations and other economic factors beyond our control. When the general level of economic activity deteriorates, our customers may delay or cancel upgrades, expansions and/or maintenance and repairs to their systems. Many factors, including the financial condition of the industry, could adversely affect our customers and their willingness to fund capital expenditures in the future. Economic, regulatory and market conditions affecting our specific end markets may adversely impact the demand for our services, resulting in the delay, reduction or cancellation of certain projects and these conditions may continue to adversely affect us in the future. We are also dependent on the amount of work our customers outsource. In a slower economy, our customers may decide to outsource less infrastructure services, reducing demand for our services. In addition, consolidation, competition or capital constraints in the industries we serve may result in reduced spending by our customers.
13
Table of Contents
Adverse credit and financial market conditions could impair our, our customers’ and our partners’ borrowing capacity, which could negatively affect us.
Our ability to generate cash is important for the funding of our operations, investing in ventures, the servicing of our indebtedness and making acquisitions. To the extent that existing cash balances and operating cash flow, together with borrowing capacity under our credit facilities, are insufficient to make investments or acquisitions or provide needed working capital, we may require additional financing from other sources. Our ability to obtain such additional financing will depend upon prevailing capital market conditions, including those arising due to events occurring in our industry, as well as conditions in our business and our operating results; and those factors may affect our efforts to negotiate terms that are acceptable to us. Furthermore, if global economic, industry, political or other market conditions adversely affect the financial institutions that provide credit to us, it is possible that our ability to establish or draw upon our credit facilities may be impacted. In addition, a downgrade in our credit rating could increase the cost of our borrowings or their refinancing, limit access to sources of financing or lead to other adverse consequences. If adequate funds are not available, or are not available on acceptable terms, we may be unable to make future investments, take advantage of acquisitions or other opportunities or respond to competitive challenges. In addition, adverse credit and financial market conditions also adversely affect our customers’ and our partners’ borrowing capacity, which could result in contract cancellations or suspensions, project award and execution delays, payment delays or defaults by our customers. These disruptions could materially impact our Backlog and profits. If we extend a significant portion of credit to our customers or projects in a specific geographic region or industry, we may experience higher levels of collection risk or non-payment if those customers are impacted by factors specific to their geographic industry or region.
The nature of our contracts subjects us to risks associated with delays and cost overruns, which may not be recoverable and may result in reduced profits or losses that could have a material impact on us.
Because our projects are often technically complex, with multiple phases occurring over several years, we incur risks in our project execution activities. These risks could result in project delays, cost overruns or other problems and can include the following:
● Unanticipated technical problems, including design or engineering issues;
14
Table of Contents
● Delays or productivity issues caused by weather; and
These and other risks may result in our failure to achieve contractual cost or schedule commitments, safety performance, overall customer satisfaction or other performance criteria. As a result, we may receive lower fees or lose our ability to earn incentive fees. In other cases, our fee will not change but we will have to continue to perform work without additional fees until the performance criteria is achieved. We may also be required to pay liquidated damages if we fail to complete a project on schedule. In addition, if we, subcontractors, suppliers or other third parties performing work or services on our behalf or supplying equipment or material on our behalf, fail to meet guaranteed performance or quality standards, we may be held responsible under the guarantee or warranty provisions of our contract for cost impact to the customer, generally in the form of contractually agreed-upon liquidated damages or an obligation to re-perform work. To the extent these events occur, the total cost to the project (including any liquidated damages we become liable to pay) could be material and could, in some circumstances, equal or exceed the full value of the contract. In such events, our financial condition or results of operations could be materially and negatively impacted.
If we are unable to accurately estimate contract risks, revenue or costs, economic factors such as inflation, the timing of new awards or the pace of project execution, we may incur a loss or achieve lower than anticipated profit.
Accounting for contract-related revenue and costs requires management to make significant estimates and assumptions that may change substantially throughout the project lifecycle, which could result in a material impact to our consolidated financial statements. In addition, cost overruns, including unanticipated cost increases on fixed price contracts could result in lower profits or losses. Economic factors, including inflation, could also subject us to higher costs, which we may not be able to fully recover in future projects that we are bidding, and could also decrease profit on our existing contracts, in particular with respect to fixed price contracts. Changes in laws, policies or regulations, including tariffs and taxes, could impact the prices for materials or equipment. Further, our results of operations have historically fluctuated, and may continue to fluctuate, quarterly and annually depending on when new awards occur and the commencement and progress of work on projects already awarded.
We may incur higher costs to lease, acquire and maintain equipment necessary for our operations.
To the extent that we are unable to buy or lease equipment necessary for a project, either due to a lack of available funding or equipment shortages in the marketplace, we may be forced to rent equipment on a short-term basis, or to find alternative ways to perform the work without the benefit of equipment ideally suited for the job, which could increase the costs of completing the project. If market rates for rental equipment increase, our margins for the project may be reduced. In addition, our equipment requires continuous maintenance, which we generally provide through our own repair facilities. If we are unable to continue to maintain the equipment in our fleet, we may be forced to obtain additional third-party repair services at a higher cost or be unable to bid on contracts.
We use certain commodity products that are subject to significant price fluctuations.
We use certain commodity products that are subject to significant price fluctuations. We are exposed to various commodity price risks, including, but not limited to, diesel fuel, natural gas, propane, steel, cement and liquid asphalt arising from transactions that are entered into in the normal course of business. We use petroleum based products, such as fuels, lubricants and liquid asphalt, to power or lubricate our equipment, and as a significant ingredient in the asphaltic concrete we manufacture for sale to third parties and use in our asphalt paving construction projects. We also use steel and other commodities in our construction projects that can be subject to significant price fluctuations. In order to manage or reduce commodity price risk, we monitor the costs of these commodities at the time of bid and price them into our contracts accordingly. Additionally, some of our contracts may include commodity price escalation clauses that partially protect us from increasing prices. We may enter into supply agreements or pre-purchase commodities to secure pricing and may use financial contracts to further manage price risk. Significant price fluctuations could have a material adverse effect on financial position, results of operations, cash flows and liquidity
15
Table of Contents
Supply chain interruptions, including availability of materials, products or equipment, may have a negative impact on our ability to complete projects.
Our ability to complete projects may be affected by supply chain disruptions. We source input materials, including raw materials, products and/or equipment, from domestic and international suppliers. While we take steps to secure delivery of the raw materials, products, and/or equipment necessary for our business operations, those measures may prove to be inadequate due to supply chain disruptions and may have a negative impact on our ability to complete projects. In some cases, the downstream effect of supply chain issues will be compounded by delays impacting our suppliers.
Some of our contracts have penalties for late completion.
In some instances, we guarantee that we will complete a project by a certain date. If we subsequently fail to complete the project as scheduled, we may be held responsible for costs resulting from the delay, generally in the form of contractually agreed-upon liquidated damages. To the extent these events occur, the total cost of the project could exceed our original estimate and we could experience reduced profits or a loss on the project, which could result in a material adverse impact to our financial position, results of operations, cash flows and liquidity.
Weather can significantly affect our revenue and profitability.
Our ability to perform work and meet customer schedules can be affected by weather conditions such as heat, wind, snow, ice, rain and named storms. Weather may affect our ability to work efficiently and can cause project delays and additional costs. Our ability to negotiate change orders for the impact of weather on a project could impact our profitability. In addition, the impact of weather can cause significant variability in our quarterly revenue and profitability.
Climate change and related environmental issues could have a material adverse impact on us.
Climate change related events, such as increased frequency and severity of storms, floods, wildfires, droughts, hurricanes, freezing conditions and other natural disasters, may have a long-term impact on our business, financial condition and results of operation. While we seek to mitigate our business risks associated with climate change, we recognize that there are inherent climate related risks regardless of where we conduct our businesses. For example, a catastrophic natural disaster could negatively impact any of our office locations and the locations of our customers or projects, has the potential to disrupt our and our customers’ businesses and may cause us to experience work stoppages, supply chain disruptions, project delays, financial losses and additional costs to resume operations, including increased insurance costs or loss of coverage, legal liability and reputational losses. Further, the risks caused by climate change span across the full spectrum of the industries we serve. The direct physical risks that climate change poses through chronic environmental changes, such as rising sea levels and temperatures, and acute events, such as hurricanes, droughts and wildfires, is common to each of these industries. Our customers could face increased costs to maintain their assets, which could result in reduced profitability and fewer resources for strategic investment. These types of physical risks could in turn lead to transitional risks (i.e., the degree to which society responds to the threat of climate change). For example, growing concerns about climate change may result in legislation, international protocols or treaties, regulation or other restrictions on greenhouse gas emissions or that otherwise seek to address climate change that could affect our customers, including those who (a) are involved in the exploration, production or refining of fossil fuels, (b) emit greenhouse gases through the combustion of fossil fuels or (c) emit greenhouse gases through the mining, manufacture, utilization or production of materials or goods. Such legislation or restrictions could increase the costs of projects for us and our customers or, in some cases, prevent a project from going forward, thereby potentially reducing the need for our services, which would in turn have a material adverse impact on us. We cannot predict when or whether any of these legislative proposals may become law or what effect will be on us and our customers.
If we are unable to attract and retain qualified managers and skilled employees, our operating costs may increase.
Our business is labor intensive and our ability to maintain our productivity and profitability may be limited by our ability to employ, train and retain skilled personnel necessary to meet our requirements. We may not be able to maintain an adequately skilled labor force necessary to operate efficiently and to support our growth strategy. We have from time-to-time experienced, and may in the future experience, shortages of certain types of qualified personnel. For example,
16
Table of Contents
periodically there are shortages of engineers, project managers, field supervisors and other skilled workers capable of working on and supervising construction projects, as well as providing engineering services. The supply of experienced engineers, project managers, field supervisors, journeyman linemen and other skilled workers may not be sufficient to meet current or expected demand. The beginning of new, large-scale infrastructure projects, or increased competition for workers currently available to us, could affect our business, even if we are not awarded such projects. Labor shortages and/or increased labor costs could impair our ability to maintain our business or grow our revenue. If we are unable to hire employees with the requisite skills, we may also be forced to incur significant training expenses.
We depend on key personnel and we may not be able to operate and grow our business effectively if we lose the services of any of our key persons or are unable to attract qualified and skilled personnel in the future.
We are dependent upon the efforts of our key personnel, and our ability to retain them and hire other qualified employees. The loss of our executive officers or other key personnel could affect our ability to run our business effectively. Competition for senior management is intense, and we may not be able to retain our personnel. The loss of any key person requires the remaining key personnel to divert immediate and substantial attention to seeking a replacement, as well as to performing the departed person’s responsibilities until a replacement is found. In addition, as some of our key persons approach retirement age, we need to provide for smooth transitions. If we fail to find a suitable replacement for any departing executive or senior officer on a timely basis, such departure could adversely affect our ability to operate and grow our business.
Our employees work on projects that are inherently dangerous and in locations where there are high security risks, and a failure to maintain a safe work site could result in significant losses.
We often work on complex projects, frequently in geographically remote or high-risk locations that are subject to political, social or economic risks or civil unrest. In those locations where we have employees or operations, we may expend significant efforts and incur substantial security costs to maintain safety. In addition, our project sites can place our employees and others near large equipment, dangerous processes or substances or highly regulated materials and in challenging environments. Safety is a primary focus of our business and is critical to our reputation and performance. Many of our customers require that we meet certain safety criteria to be eligible to bid on contracts, and some of our contract fees or profits are subject to satisfying safety criteria. Unsafe work conditions also have the potential of increasing employee turnover, increasing project costs and raising our operating costs. If we fail to implement appropriate safety procedures and/or if our procedures fail, our employees or others may suffer injuries or loss of life, the completion of a project could be delayed and we could experience investigations or litigation. Although we have a safety function to implement effective health, safety and environmental procedures throughout our company, the failure to comply with such procedures, customer contracts or applicable regulations could subject us to losses and liability. Despite these activities we cannot guarantee the safety of our personnel, nor can we guarantee our work, equipment or supplies will be free from damage.
We may incur liabilities or suffer negative financial or reputational impacts relating to health and safety matters.
Our operations are subject to extensive laws and regulations relating to the maintenance of safe conditions in the workplace. While we have invested, and will continue to invest, substantial resources in our environmental, health and safety programs, our industry involves a high degree of operational risk and there can be no assurance that we will avoid significant liability exposure. Serious accidents, including fatalities, may subject us to substantial penalties, civil litigation or criminal prosecution. Claims for damages to persons, including claims for bodily injury or loss of life, could result in substantial costs and liabilities, which could materially and adversely affect our financial condition, results of operations or cash flows. In addition, if our safety record were to substantially deteriorate over time or we were to suffer substantial penalties or criminal prosecution for violation of health and safety regulations, our customers could cancel our contracts and not award us future business.
We are dependent upon suppliers and subcontractors to complete many of our contracts.
Some of the work performed under our contracts is performed by third-party subcontractors. We also rely on third-party suppliers to provide certain equipment and materials used for projects. If we are unable to hire qualified
17
Table of Contents
subcontractors or find qualified suppliers, our ability to successfully or timely complete a project could be impaired. If the amount we are required to pay for subcontractors or equipment and supplies exceeds what we have estimated, we may suffer losses on these contracts. If a supplier or subcontractor fails to provide supplies, technology, equipment or services as required under a contract to us, our joint venture partner, our customer or any other party involved in the project, or provides supplies, technology, equipment or services that are not an acceptable quality, we may be required to source those supplies, technology, equipment or services on a delayed basis or at a higher price than anticipated, which could impact our profitability. In addition, faulty workmanship, equipment or materials could impact the project, resulting in claims against us for failure to meet required project specifications. These risks may be intensified during an economic downturn if these suppliers or subcontractors experience financial difficulties or find it difficult to obtain sufficient financing to fund their operations or access to bonding and are not able to provide the services or supplies necessary for our business. In addition, in instances where we rely on a limited number of suppliers or subcontractors, there may be no available replacement technology, equipment, materials or services on a timely basis or at the costs we had anticipated. A failure by a third-party subcontractor or supplier to comply with applicable laws, rules or regulations could negatively impact our business and reputation and could result in fines, penalties or suspension.
Our participation in joint ventures exposes us to liability and/or harm to our reputation for failures by our partners.
As part of our business, we enter into joint venture arrangements, typically to jointly bid on and execute particular projects, thereby reducing our risk profile while enhancing execution capabilities and increasing surety bonding capacity. Success on these joint projects depends in large part on whether our joint venture partners satisfy their contractual obligations. Generally, we and our joint venture partners are jointly and severally liable for all liabilities and obligations of our joint ventures. If a joint venture partner fails to perform or is financially unable to bear its portion of required capital contributions or other obligations, including liabilities stemming from lawsuits, we could be required to make additional investments, provide additional services or pay more than our proportionate share of a liability to make up for our partner’s shortfall. Further, if we are unable to adequately address our partner’s performance issues, the customer may terminate the project, which could result in legal liability to us, harm our reputation, reduce our profit on a project or result in a loss.
Employee, agent or partner misconduct or our overall failure to comply with laws or regulations could impair our ability to compete for contracts.
Misconduct, fraud, non-compliance with applicable laws and regulations or other improper activities by one of our employees, agents or partners could have a significant negative impact on our business and reputation. Such misconduct could include the failure to comply with anti-corruption, export control and environmental regulations, federal procurement regulations, regulations regarding the pricing of labor and other costs in government contracts, regulations regarding the protection of sensitive government information, regulations on lobbying or similar activities, regulations pertaining to internal control over financial reporting and various other applicable laws or regulations. The precautions we take to prevent and detect fraud, misconduct or failures to comply with applicable laws and regulations may not be effective, and we could face unknown risks or losses. Failure to comply with applicable laws or regulations or acts of fraud or misconduct could subject us to fines and penalties, loss of security clearance and suspension or debarment from contracting with government agencies, which could weaken our ability to win contracts and have a material adverse impact on our revenues and profits.
Changes in laws or regulations, or a failure to comply with any laws and regulations, may adversely affect our business, investments and results of operations.
We are subject to laws and regulations enacted by national, regional and local governments. Compliance with, and monitoring of, applicable laws and regulations may be difficult, time consuming and costly. Those laws and regulations and their interpretation and application may also change from time to time and those changes could have a material adverse effect on our business, investments and results of operations. In addition, a failure to comply with applicable laws or regulations, as interpreted and applied, could result in fines, revocation of operating licenses or permits, injunctive relief or similar remedies, as well as give rise to termination or cancellation rights under our contracts or disqualify from future bidding opportunities, which could be costly to us or limit our ability to operate.
18
Table of Contents
We could be adversely affected by violations of the U.S. Foreign Corrupt Practices Act and similar worldwide anti-bribery laws.
The U.S. Foreign Corrupt Practices Act and similar anti-bribery laws in other jurisdictions generally prohibit companies and their intermediaries from making improper payments to officials or others for the purpose of obtaining or retaining business. While our policies mandate compliance with these anti-bribery laws, we operate in many parts of the world that have experienced corruption to some degree and, in certain circumstances, strict compliance with anti-bribery laws may conflict with local customs and practices. We train our personnel concerning anti-bribery laws and issues, and we also inform our partners, subcontractors, suppliers, agents and others who work for us or on our behalf that they must comply with anti-bribery law requirements. We also have procedures and controls in place to monitor compliance. However, there is no assurance that our internal controls will always protect us from the possible reckless or criminal acts committed by our employees or agents. If we are found to be liable for anti-bribery law violations (either due to our own acts or our inadvertence, or due to the acts or inadvertence of others including our partners, agents, subcontractors or suppliers), we could suffer from criminal or civil penalties or other sanctions, including contract cancellations or debarment, and damaged reputation, any of which could have a material adverse effect on our business. Litigation or investigations relating to alleged or suspected violations of anti-bribery laws, even if ultimately such litigation or investigations demonstrate that we did not violate anti-bribery laws, could be costly and could distract management.
During the ordinary course of our business, we may become subject to material lawsuits or indemnity claims.
We have in the past been, and may in the future be, named as a defendant in lawsuits, claims and other legal proceedings during the ordinary course of our business. These actions may seek, among other things, compensation for alleged personal injury, workers’ compensation, employment discrimination, breach of contract, cyber-security and related incidents, property damage, punitive damages and civil penalties or other losses or injunctive or declaratory relief. In addition, we generally indemnify our customers for claims related to the services we provide and actions we take under our contracts with them, and, in some instances, we may be allocated risk through our contract terms for actions by our customers or other third parties. Because our services in certain instances may be integral to the operation and performance of our customers’ infrastructure, we may become subject to lawsuits or claims for any failure of the systems on which we work, even if our services are not the cause of such failures, and we could be subject to civil and criminal liabilities to the extent that our services contributed to any property damage, personal injury or system failure. The outcome of any of these lawsuits, claims or legal proceedings could result in significant costs and diversion of management’s attention from the business. Payments of significant amounts, even if reserved, could adversely affect our reputation, our cash flows and our business.
Systems and information technology interruption and breaches in data security and/or privacy could adversely impact our ability to operate and negatively impact our results of operations.
We rely on computer, information and communication technology and other related systems, some of which are hosted by third party providers, for various business processes and activities, including project management, accounting, financial reporting and business development. These systems have been and may, in the future, be subject to interruptions or damage by a variety of factors including, but not limited to, cyber-attacks and ransomware, natural disasters, power loss, telecommunications failures, acts of war, computer viruses, email phishing, corporate espionage, obsolescence and physical damage. Such interruptions can result in a loss of critical data, a delay in operations, damage to our reputation or an unintentional disclosure of customer confidential or personally identifiable information, any of which could have a material adverse impact on us and our operating results. Cybersecurity risks include potential attacks on both our information technology infrastructure and those of third parties (both on premises and in the cloud) attempting to gain unauthorized access to our confidential or other proprietary information, classified information or information relating to our employees, customers and other third parties. We dedicate considerable attention and resources to the safeguarding of our information technology systems. Nevertheless, due to the evolving nature, persistence, sophistication and volume of cyber-attacks, we may not be successful in defending our systems against all such attacks. Consequently, we have employed, and may need to continue to employ, significant resources to remediate the impact of, or further mitigate the risk of, such an attack. Any successful cyber-attack can result in the criminal, or otherwise illegitimate use of, confidential data, including our data or third-party data for which we have the responsibility for safekeeping. Additionally, such an attack could have a material adverse impact on our operations, reputation and financial results. In addition, various privacy
19
Table of Contents
and security laws and regulations requiring us to protect sensitive and confidential information from disclosure continue to evolve and pose increasingly complex compliance challenges. Compliance with evolving data privacy laws and regulations may cause us to incur additional costs, and any violation could result in damage to our reputation and/or subject us to fines, payment of damages, lawsuits and restrictions on our use of data, which could have a material adverse impact on our results of operations.
Our inability to recover on contract modifications against project owners or subcontractors for payment or performance could negatively affect our business.
We periodically present contract modifications to our customers and subcontractors for changes in contract specifications or requirements. We consider unapproved change orders to be contract modifications for which customers have not agreed to both scope and price. We consider claims to be contract modifications for which we seek, or will seek, to collect from customers, or others, for customer-caused changes in contract specifications or design or other customer-related causes of unanticipated additional contract costs on which there is no agreement with customers. Claims can also be caused by non-customer-caused changes, such as rain or other weather delays. In some cases, settlement of contract modifications may not occur until after completion of work under the contract. A failure to promptly document and negotiate a recovery for contract modifications could have a negative impact on our cash flows, and an overall inability to recover contract modifications could have a negative impact on our financial condition, results of operations and cash flows.
Our failure to adequately recover on affirmative claims brought by us against project owners or other project participants for additional contract costs could have a negative impact on our liquidity and future operations.
In certain circumstances, we assert affirmative claims to which we believe the Company is entitled against project owners, engineers, consultants, subcontractors or others involved in a project for additional costs exceeding the contract price or for amounts not included in the original contract price. These types of affirmative claims occur due to matters such as, but not limited to, delays or changes from the initial project scope, or differing site conditions, incomplete or inaccurate plans and drawings, which may result in additional costs. Often, these affirmative claims can be the subject of lengthy arbitration or litigation proceedings, and it is difficult to accurately predict when and on what terms they will be fully resolved. The potential gross profit impact of recoveries for affirmative claims may be material in future periods when they, or a portion of them, become probable and estimable or are settled. When these types of events occur, we use working capital to cover cost overruns pending the resolution of the relevant affirmative claims and may incur additional costs when pursuing such potential recoveries. A failure to recover on these types of affirmative claims promptly and fully could have a negative impact on our financial position, results of operations, cash flows and liquidity. In addition, while customers and subcontractors may be obligated to indemnify us against certain liabilities, such third parties may refuse or be unable to pay us.
We may experience delays and defaults in customer payments, and we may pay our suppliers and subcontractors before receiving payment from our customers for the related services, which could result in a material adverse effect on our business.
We use subcontractors and material suppliers for portions of certain work, and our customers pay us for those related services. If we pay our suppliers and subcontractors for materials purchased and work performed for customers who fail to pay us, or such customers delay paying us for the related work or materials, we could experience a material adverse effect on our business and financial performance. In addition, if customers fail to pay us for work we perform, we could experience a material adverse effect on our business and profitability.
The COVID-19 pandemic has adversely impacted, and could continue to adversely impact, our business, financial condition and results of operations.
The COVID-19 pandemic had created volatility, uncertainty and economic disruption for the Company, our customers, subcontractors and suppliers and the markets in which we do business. The scope and impact of the COVID-19 pandemic continues to evolve, and new strains of the COVID-19 virus have emerged. As a result of the COVID-19 pandemic, we have experienced delays in certain bidding activities and contract awards and also in legal proceedings and
20
Table of Contents
settlement discussions where we have claims against project owners or customers. Consequently, our ability to resolve and recover on these types of claims has been and may continue to be delayed, which may adversely affect our liquidity and financial results. It remains difficult to assess the full impact that the COVID-19 pandemic may have on our business, including the impact of actions that may continue to be taken in response to the pandemic and the impacts that the pandemic will have on our employees, our operating segments and practices, our customers, subcontractors and suppliers and the regions that we serve, or on our financial condition and results of operations as a whole. The full impact depends on many factors that remain uncertain and subject to ongoing volatility, or that are not yet identifiable, and in many cases are out of our control. The COVID-19 pandemic and the volatile economic conditions stemming from the pandemic, as well as reactions to future pandemics or resurgences of COVID-19, could also aggravate or heighten the risks posed by other risk factors that we have identified herein, which in turn could materially and adversely affect our business, financial condition and results of operations. There may be other adverse consequences to our business, financial condition and results of operations from the spread of COVID-19 that are not presently known or that have not yet become apparent. As a result, we cannot provide any assurance that the COVID-19 pandemic would not have a further adverse impact on our business, financial condition and results of operations.
In connection with acquisitions or divestitures, we may become subject to liabilities.
In connection with any acquisitions, we may acquire liabilities or defects such as legal claims, including but not limited to third party liability and other tort claims, claims for breach of contract, employment-related claims, environmental liabilities, conditions or damage, permitting, regulatory or other compliance with law issues or tax liabilities. If we acquire any of these liabilities and they are not adequately covered by insurance or an enforceable indemnity or similar agreement from a creditworthy counterparty, we may be responsible for significant out-of-pocket expenditures. In connection with any divestitures, we may incur liabilities for breaches of representations and warranties or failure to comply with operating covenants under any agreement for a divestiture. We may also retain exposure on financial or performance guarantees, contractual, employment, pension and severance obligations or other liabilities of the divested business and potential liabilities that may arise under law because of the disposition or the subsequent failure of an acquiror. As a result, performance by the divested businesses or other conditions outside of our control could have a material adverse effect on our business, financial condition and results of operations. In addition, we may indemnify a counterparty in a divestiture for certain liabilities of the divested business or operations subject to the divestiture transaction. These liabilities, if they materialize, could have a material adverse effect on our business, financial condition and results of operations.
If we fail to integrate acquisitions successfully, we may experience operational challenges and risks, which may have an adverse effect on our business.
As part of our business strategy, we may acquire companies that expand, complement or diversify our business. Acquisitions may expose us to operational challenges and risks, including, among others:
● The assimilation of new employees and the integration of business cultures;
● Retaining key personnel;
● Challenges in keeping existing customers and obtaining new customers;
● Challenges in combining service offerings and sales and marketing activities;
● The potential impairment of acquired goodwill and intangible assets; and
21
Table of Contents
● The inability to enforce covenants not to compete.
Failure to effectively manage the integration process could adversely impact our business, financial condition, results of operations and cash flows.
Our financial results are based upon estimates and assumptions that may differ from actual results.
In preparing our consolidated financial statements in conformity with generally accepted accounting principles, many estimates and assumptions are used in determining the reported revenue, costs and expenses recognized during the periods presented and disclosures of contingent assets and liabilities known to exist as of the date of the financial statements. These estimates and assumptions must be made because certain information that is used in the preparation of our financial statements cannot be calculated with a high degree of precision from data available, is dependent on future events or is not capable of being readily calculated based on generally accepted accounting principles. Often times, these estimates are particularly difficult to determine, and we must exercise significant judgment. Estimates may be used in estimated contract values and estimated costs at completion, our assessments of the allowance for doubtful accounts, useful lives of property and equipment, fair value assumptions in analyzing goodwill and long-lived asset impairments, self-insured claims liabilities, accounting for revenue recognized over time and provisions for income taxes. Actual results could differ materially from the estimates and assumptions that we use.
Our reported results of operations could be adversely affected as a result of impairments of goodwill, other identifiable intangible assets or investments.
When we acquire a business, we record an asset called “goodwill” for the excess amount we pay for the business over the net fair value of the tangible and identifiable intangible assets of the business we acquire. Under current accounting rules, goodwill and other identifiable intangible assets that have indefinite useful lives cannot be amortized, but instead must be tested at least annually for impairment, while identifiable intangible assets that have finite useful lives are amortized over their useful lives. Significant judgment is required in completing these tests. Any impairment of the goodwill or identifiable intangible assets recorded in connection with could negatively impact our results of operations. In addition, we may enter into various types of investment arrangements, such as an equity interest we hold in a business entity. Equity investments are reviewed for impairment by assessing whether any decline in the fair value of the investment below its carrying value is other than temporary. In making this determination, factors such as the ability to recover the carrying amount of the investment and the inability of the investee to sustain future earnings capacity are evaluated in determining whether an impairment should be recognized.
Our accounting for revenue recognized over time could result in a reduction or elimination of previously reported revenue and profit.
For contracts where scope is adequately defined, and therefore we can reasonably estimate total contract value, we recognize revenue over time as work is completed. Accounting for long-term contracts involves the use of various techniques to estimate total transaction price and costs. For long-term contracts, transaction price, estimated cost at completion and total costs incurred to date are used to calculate revenue earned. Unforeseen events and circumstances can alter the estimate of the costs and potential profit associated with a particular contract. Total estimated costs, and thus contract revenue and income, can be impacted by changes in productivity, scheduling, the unit cost of labor, subcontracts, materials and equipment. Additionally, external factors such as weather, customer needs, customer delays in providing permits and approvals, labor availability, governmental regulation and politics may affect the progress of a project’s completion, and thus the timing of revenue recognition. Actual results could differ from estimated amounts and could result in a reduction or elimination of previously recognized earnings. It is possible that such adjustments could be significant and could have an adverse effect on our business.
22
Table of Contents
Our indebtedness could lead to adverse consequences or adversely affect our financial position and prevent us from fulfilling our obligations under such indebtedness, and any refinancing of this debt could be at significantly higher interest rates.
Our indebtedness could have important consequences, including but not limited to:
Our ability to service our debt will depend on our future operating performance and financial results, which may be subject to factors beyond our control, including general economic, financial and business conditions. If we do not have sufficient cash flow to service our debt, we may need to refinance all or part of our existing debt, borrow more money or sell securities or assets, some or all of which may not be available to us at acceptable terms or at all. In addition, we may need to incur additional debt in the future in the ordinary course of business. Our current debt and any future additional debt we may incur may impose significant operating and financial restrictions on us. A breach of any of these restrictions, including restrictions related to debt covenants, could result in a default. If a default occurs, the relevant lenders could elect to accelerate payments due. If our operating performance declines, or if we are unable to comply with any restrictions, we may need to obtain amendments to our credit agreements or waivers from the lenders to avoid default. These factors could have a material adverse effect on us.
Our bonding requirements may limit our ability to incur indebtedness, which could limit our ability to refinance our existing credit facilities or to execute our business plan.
Our ability to obtain surety bonds depends upon various factors including our capitalization, working capital, past performance, credit rating, tangible net worth, amount of our indebtedness, overall capacity of the surety market and other factors. In order to obtain required bonds, we may be limited in our ability to incur additional indebtedness that may be needed to refinance our existing credit facilities upon maturity, to complete acquisitions and to otherwise execute our business plans.
We may be unable to win new contracts if we cannot provide customers with letters of credit or performance or other bonds.
For many of our customers, surety bonds provide an adequate form of security, but for some customers security in the form of a letter of credit may be required. Failure to provide either a bond or a letter of credit when required by a customer may result in our inability to compete for, win or retain a project.
It can be difficult and expensive to obtain the insurance we need for our business operations.
We maintain insurance both as a risk management strategy and to satisfy the requirements of many of our contracts. Although we have been generally able to cover our insurance needs, there can be no assurances that we can secure all necessary or appropriate insurance in the future or that such insurance can be economically secured. For example, catastrophic events can result in decreased coverage limits, more limited coverage or increased premium costs or deductibles. We also monitor the financial health of our insurance. If any of our third party insurers fail, abruptly cancel our coverage or otherwise cannot satisfy their obligations to us, then our overall risk exposure and operational expenses could increase and our business operations could be interrupted.
23
Table of Contents
We have international operations that are subject to foreign economic and political uncertainties and risks. Unexpected and adverse changes in the foreign countries in which we operate could result in project disruptions, increased cost and potential losses.
Our business is subject to international economic and political conditions that may change for reasons that are beyond our control. Operating in the international marketplace exposes us to a number of risks including:
● Embargoes or other trade restrictions, including sanctions;
● Restrictions on currency movement;
● Tax or tariff changes and withholding requirements;
● Currency exchange rate fluctuations;
● Natural disasters and public health crises, including pandemics;
● Expropriation and nationalization of our assets;
● International hostilities; and
● Unrest, civil strife, acts of war, terrorism and insurrection.
Our level of exposure to these risks may vary with each project, depending on the location of the project and its stage of completion. To the extent that our international business is affected by unexpected and adverse foreign economic and political conditions and risks, we may experience project disruptions and losses. Net assets of foreign operations for the years ended December 31, 2024, and December 31, 2023, are approximately 62% and 47%, respectively, of our total net assets.
Foreign currency risks could have an adverse impact on revenue, earnings and/or Backlog.
Our contracts may subject us to foreign currency risk, particularly when project revenue is denominated in a currency different than the expected costs. A project may be denominated in different currencies at various points in time as a project progresses. We may attempt to minimize our exposure to foreign currency risk by obtaining contract provisions that protect us from foreign currency fluctuations and/or by implementing hedging strategies utilizing derivatives. However, these actions may not always eliminate all foreign currency risk, and as a result, our profitability could be affected. In addition, the U.S. dollar value of our Backlog may from time to time increase or decrease significantly due to foreign currency volatility. We may also be exposed to limitations on our ability to reinvest earnings from operations in one country to fund our operations in other countries.
We could be adversely impacted if we fail to comply with domestic and international import and export laws.
Our international operations require importing and exporting goods and technology across international borders on a regular basis. Our policies mandate strict compliance with U.S. and foreign international trade laws. To the extent we export technical services, data and products outside of the U.S., we are subject to laws and regulations governing international trade and exports. A failure to comply with these laws and regulations could result in civil or criminal sanctions, including the imposition of fines, the denial of export privileges and suspension or debarment from participation in federal contracts.
24
Table of Contents
Compliance with and changes in tax laws could adversely affect our performance.
We are subject to extensive tax liabilities imposed by multiple jurisdictions, including federal, state, local and international jurisdictions. New tax laws and regulations and changes in existing tax laws and regulations are continuously being enacted or proposed and could result in a different tax rate on our earnings, which could have a material impact on our earnings and cash flow from operations. In addition, significant judgment is required in determining our provision for income taxes. In the ordinary course of our business, there are some transactions and calculations where the ultimate tax determination is uncertain. We are regularly subject to audits by tax authorities, and our tax estimates and tax positions could be materially affected by many factors, including the final outcome of tax audits and related litigation, the introduction of new tax accounting standards, legislation, regulations and related interpretations, our mix of earnings, the realizability of deferred tax assets and changes in uncertain tax positions. A significant increase in our tax rate could have a material adverse effect on our profitability and liquidity.
Bank failures or intervention by banking regulators may have an adverse impact on our business.
Bank failures or intervention by banking regulators with respect to bank closures, legislation or regulation, and reaction to systemic risk assessments in the national and international banking industries may adversely affect our access to capital, which may adversely impact our operational and financial results. Bank failures may cause financial losses where deposits are held in excess of Federal Deposit Insurance Corporation, or other, insured limits. Bank failures, or changes in legislation and regulation, may adversely impact other entities that would, in turn, impact us. If our joint venture partners, insurers, sureties, customers, suppliers, or other parties on whom we rely are affected by issues in the banking industry it may have an adverse impact on our operational and financial performance.
Delaware law and our charter documents may impede or discourage a takeover or change in control.
Anti-takeover provisions under Delaware law may impose an impediment to the ability of others to acquire control of us, even if a change of control would be of benefit to our stockholders. In addition, certain provisions of our Certificate of Incorporation and Bylaws also may impose an impediment or discourage others from a takeover. These provisions include, but are not limited to, restrictions on the ability of a stockholder to call a special meeting or nominate a director for election and our Board of Directors’ ability to authorize the issuance of preferred shares. These types of provisions may limit the ability of stockholders to obtain a premium for their shares and may make it more difficult for a third party to acquire us, even if the acquisition would be beneficial to our stockholders.
Risks Relating to Our Securities
We are an “emerging growth company” and it cannot be ascertained whether the reduced disclosure requirements applicable to emerging growth companies will make our Common Stock less attractive to investors.
We are an “emerging growth company” as defined in Section 2(a)(19) of the Securities Act. As an emerging growth company, we are only required to provide two years of audited financial statements and only two years of related selected financial data and management discussion and analysis of financial condition and results of operations disclosure. In addition, we are not required to obtain auditor attestation of its reporting on internal control over financial reporting, have reduced disclosure obligations regarding executive compensation and are not required to hold non-binding advisory votes on executive compensation. In addition, Section 13(a) of the Exchange Act provides that an emerging growth company can take advantage of an extended transition period for complying with new or revised accounting standards. We intend to take advantage of the extended transition period for adopting new or revised accounting standards under the JOBS Act as an emerging growth company. As a result of this election, our consolidated financial statements may not be comparable to companies that comply with public company effective dates. We cannot predict whether investors will find our Common Stock to be less attractive as a result of any reliance on these exemptions. If some investors find our Common Stock to be less attractive, there may be a less active trading market for our Common Stock and the price of our Common Stock may be more volatile.
We will remain an emerging growth company until the earliest of: (i) the end of the fiscal year in which we have total annual gross revenue in excess of $1.235 billion; (ii) the last day of our fiscal year following the fifth anniversary of
25
Table of Contents
the date on which we consummated our initial public offering (the “IPO”) (or December 31, 2026); (iii) the date on which we issue more than $1.0 billion in non-convertible debt during the preceding three-year period; or (iv) the end of the fiscal year in which the market value of our Common Stock held by non-affiliates equals or exceeds $700 million as of the last business day of our most recently completed second fiscal quarter.
Further, there is no guarantee that the exemptions described above available under the Exchange Act will result in significant savings. To the extent that we choose not to use exemptions from various reporting requirements under the Exchange Act, we will incur additional compliance costs, which may impact our financial condition.
An established market for our securities may not be sustained.
An active trading market for our securities may not be sustained. Additionally, as described further below, if our securities become delisted from NYSE for any reason, and are quoted on the OTC Bulletin Board, an inter-dealer automated quotation system for equity securities not listed on a national exchange, the liquidity and price of our securities may be more limited than if we were listed on NYSE or another national exchange. You may be unable to sell your securities unless a market can be established and sustained.
The price of our securities may vary significantly due to a variety of reasons including but not limited to recession, shortages of durable and hard goods used at our properties, changes in interest rates, natural disasters and general market or economic conditions. Additionally, the initial stockholders of Legato II (the “Initial Stockholders”) and current and former management control a majority of our shares which will result in limited liquidity of our securities. This could subject our securities to additional volatility.
NYSE may delist Southland’s securities from trading on its exchange, which could limit investors’ ability to make transactions in its securities and subject Southland to additional trading restrictions.
Currently, our Common Stock and Warrants are publicly traded on NYSE. We may be unable to maintain the listing of our securities in the future. In order to continue listing our securities on NYSE, we will be required to maintain certain financial, distribution and stock price levels.
If NYSE delists our securities from trading on its exchange and we are not able to list our securities on another national securities exchange, our securities may be quoted on an over-the-counter market. If this were to occur, we could face significant material adverse consequences, including:
● a limited availability of market quotations for our securities;
● reduced liquidity for our securities;
● a limited amount of news and analyst coverage; and
The National Securities Markets Improvement Act of 1996 (the “NSMIA”), which is a federal statute that prevents or preempts the states from regulating the sale of certain securities, which are referred to as “covered securities.” Since our Common Stock and Warrants are listed on NYSE, they are covered securities. Although the states are preempted from regulating the sale of covered securities, the NSMIA does allow the states to investigate companies if there is a suspicion of fraud, and, if there is a finding of fraudulent activity, then the states can regulate or bar the sale of covered securities in a particular case. Further, if our securities were no longer listed on NYSE, they would not be covered securities and would be subject to regulation in each state in which they are offered.
26
Table of Contents
The price of our securities may change significantly, and you could lose all or part of your investment as a result.
The trading price of our securities is likely to be volatile. The stock market recently has experienced volatility. This volatility often has been unrelated or disproportionate to the operating performance of particular companies. You may not be able to resell your securities at an attractive price due to a number of factors, including, but not limited to, the following:
● results of operations that vary from those of our competitors;
● declines in the market prices of securities generally;
● strategic actions by us or our competitors;
● any significant change in our management;
● future sales of our Common Stock or other securities;
● actions by institutional or activist stockholders;
These broad market and industry fluctuations may adversely affect the market price of our securities, regardless of our actual operating performance. In addition, price volatility may be greater if the public float and trading volume of our securities is low.
In the past, following periods of market volatility, stockholders have instituted securities class action litigation. If we were involved in securities litigation, it could have a substantial cost and divert resources and the attention of executive management from our business regardless of the outcome of such litigation.
27
Table of Contents
Future sales, or the perception of future sales, by the Company or our stockholders in the public market could cause the market price of our securities to decline.
If we or our stockholders sell or indicate an intention to sell substantial amounts of our securities in the public market, the trading price of our securities could decline. In addition, shares underlying any outstanding options and restricted stock units will become eligible for sale if exercised or settled, as applicable, to the extent permitted by the provisions of various vesting agreements and Rule 144 of the Securities Act. All the shares of Common Stock reserved for issuance under our equity incentive plan are registered on Form S-8 under the Securities Act and upon issuance, are eligible for sale in the public markets, subject to Rule 144 limitations applicable to affiliates. If these shares are sold, or if it is perceived that they will be sold, in the public market, the trading price of our Common Stock could decline.
The Initial Stockholders and Southland Members are not subject to contractual restrictions regarding the transfer of their shares of Common Stock. The market price of our Common Stock could decline if such holders sell their shares or are perceived by the market as intending to sell them.
If securities analysts do not publish research or reports about our business or if they downgrade our stock or our sector, the price and trading volume of our securities could decline.
The trading market for our securities will rely in part on the research and reports that industry or financial analysts publish about the Company or its business. We have no control over such analysts and their reports relating to our business. In addition, some financial analysts may have limited expertise with our model and operations. Furthermore, if one or more of the analysts who do cover the Company downgrade our securities or our industry, or the securities of any of our competitors, or publish inaccurate or unfavorable research about our business, the price of our securities could decline. If one or more of these analysts ceases coverage of the Company or fails to publish reports on it regularly, we could lose visibility in the market, which in turn could cause the price or trading volume of our securities to decline.
Our actual operating and financial results in any given period may differ from guidance we provide to the public, including our most recent public guidance.
From time to time, in press reports, SEC filings, public conference calls and other contexts, we have provided guidance to the public regarding current business conditions and our expectations for our future financial results. We expect that we will provide guidance periodically in the future. Such guidance would be based upon a number of assumptions, expectations and estimates that would be inherently subject to significant business, economic and competitive uncertainties and contingencies, many of which would be beyond our control. In providing guidance, we would also make various assumptions with respect to our future business decisions, some of which will change. Our actual financial results, therefore, may vary from our guidance due to our inability to meet the assumptions upon which such guidance is based and the impact on our business of various risks and uncertainties described in these risk factors and in our public filings with the SEC. Variances between our actual results and our guidance may be material. To the extent that our actual financial results do not meet or exceed its guidance, the trading prices of our securities may be materially adversely affected.
We do not intend to pay dividends for the foreseeable future. As a result, you will be relying solely on the appreciation in value of our securities to achieve a return on your investment.
We intend to retain all of our earnings for the foreseeable future to finance the operation and expansion of our business and do not anticipate paying cash dividends on our securities. As a result, you can expect to receive a return on your investment in our securities only if the market price of such securities increases.
We are a “controlled company” that could take advantage of exemptions to certain corporate governance requirements under NYSE rules in the future.
We are a “controlled company” within the meaning of the NYSE listing standards. Under these rules, a company of which more than 50% of the voting power is held by an individual, a group or another company is a
28
Table of Contents
“controlled company” and may elect not to comply with certain corporate governance requirements of the NYSE, including (i) the requirement that a majority of the board of directors consist of independent directors, (ii) the requirement that we have a nominating and corporate governance committee that is composed entirely of independent directors with a written charter addressing the committee’s purpose and responsibilities and (iii) the requirement that we have a compensation committee that is composed entirely of independent directors with a written charter addressing the committee’s purpose and responsibilities. Although we meet the definition of a “controlled company,” we have determined at this time not to take advantage of this designation and comply with all the corporate governance rules applicable to listed companies that are not controlled companies. We may, however, determine to take advantage of these exemptions in the future. If we did, you would not have the same protections afforded to stockholders of companies subject to all of the corporate governance requirements of the NYSE.
The Warrants may never be in the money, and may expire worthless.
We believe the likelihood that Warrant holders will exercise their Warrants, and therefore the amount of cash proceeds that we would receive, is dependent upon the trading price of our Common Stock. To the extent the market price of our Common Stock remains below the exercise price of $11.50 per share, we believe that Warrant holders will be unlikely to exercise their Warrants for cash, resulting in little or no cash proceeds to us for any such exercise. There is no way to ensure that the market price of our Common Stock will exceed the exercise price of the Warrants following the time they become exercisable and prior to their expiration. As a result, the Warrants may expire worthless, and we may not receive any proceeds from the exercise of the Warrants.
If we do not maintain a current and effective prospectus relating to the Common Stock issuable upon exercise of the Warrants, holders will only be able to exercise such Warrants on a “cashless basis.”
If we do maintain a current and effective prospectus relating to the Common Stock issuable upon exercise of the Warrants at the time that holders wish to exercise such Warrants, they will only be able to exercise them on a “cashless basis” provided that an exemption from registration is available. As a result, the number of shares of Common Stock that holders will receive upon exercise of the Warrants will be fewer than it would have been had such holder exercised his Warrant for cash. Further, if an exemption from registration is not available, holders would not be able to exercise on a cashless basis and would only be able to exercise their Warrants for cash if a current and effective prospectus relating to the Common Stock issuable upon exercise of the warrants is available. Under the terms of that certain Warrant Agreement (the “Warrant Agreement”), dated November 22, 2021, entered into between the Company and Equiniti Trust Company, LLC (f/k/a American Stock Transfer & Trust Company), as warrant agent, we have agreed to use our best efforts to meet these conditions and to file and maintain a current and effective prospectus relating to the Common Stock issuable upon exercise of the Warrants until the expiration of the Warrants. However, we cannot provide assurances that we will be able to do so. If we are unable to do so, the potential “upside” of the holder’s investment in our company may be reduced or the Warrants may expire worthless.
An investor will only be able to exercise a Warrant if the issuance of shares of Common Stock upon such exercise has been registered or qualified or is deemed exempt under the securities laws of the state of residence of the holder of the Warrants.
No Warrants will be exercisable and we will not be obligated to issue shares of Common Stock unless the shares of Common Stock issuable upon such exercise has been registered or qualified or deemed to be exempt under the securities laws of the state of residence of the holder of the Warrants. If the shares of Common Stock issuable upon exercise of the Warrants are not qualified or exempt from qualification in the jurisdictions in which the holders of the warrants reside, the Warrants may be deprived of any value, the market for the Warrants may be limited and they may expire worthless if they cannot be sold.
We may amend the terms of the Warrants in a manner that may be adverse to holders with the approval by the holders of at least a majority of the then outstanding Warrants.
Our Warrants have been issued in registered form under the Warrant Agreement. The Warrant Agreement provides that the terms of the Warrants may be amended without the consent of any holder to cure any ambiguity or correct
29
Table of Contents
any defective provision. The Warrant Agreement requires the approval by the holders of at least a majority of the then outstanding Warrants in order to make any change that adversely affects the interests of the registered holders.
We may redeem unexpired Warrants prior to their exercise at a time that is disadvantageous to the holders, thereby making the Warrants worthless.
We have the ability to redeem outstanding Warrants at any time after they become exercisable and prior to their expiration, at a price of $0.01 per warrant, provided that the last reported sales price of Common Stock equals or exceeds $18.00 per share (as adjusted for stock splits, stock dividends, reorganizations and recapitalizations) for any 20 trading days within a 30 trading-day period commencing at any time after the Warrants become exercisable and ending on the third business day prior to proper notice of such redemption provided that on the date we give notice of redemption and during the entire period thereafter until the time we redeem the Warrants, we have an effective registration statement under the Securities Act covering the shares of Common Stock issuable upon exercise of the Warrants and a current prospectus relating to them is available. If and when the Warrants become redeemable by us, we may exercise our redemption right even if we are unable to register or qualify the underlying securities for sale under all applicable state securities laws. Redemption of the outstanding Warrants could force holders (i) to exercise their Warrants and pay the exercise price therefor at a time when it may be disadvantageous to do so, (ii) to sell their Warrants at the then-current market price when they might otherwise wish to hold their Warrants or (iii) to accept the nominal redemption price which, at the time the outstanding Warrants are called for redemption, is likely to be substantially less than the market value of their Warrants.
Our management’s ability to require holders of our Warrants to exercise such Warrants on a cashless basis will cause holders to receive fewer shares of common stock upon their exercise of the warrants than they would have received had they been able to exercise their warrants for cash.
If we call our Warrants for redemption, our management will have the option to require any holder that wishes to exercise his Warrant (including any Private Warrants) to do so on a “cashless basis.” If our management chooses to require holders to exercise their Warrants on a cashless basis, the number of shares of common stock received by a holder upon exercise will be fewer than it would have been had such holder exercised his warrant for cash. This will have the effect of reducing the potential “upside” of the holder’s investment in our company.
We may issue additional equity securities and any such issuance may dilute earnings per share and stockholders’ percentage ownership.
We may in the future issue additional equity securities to pay for potential acquisitions or to otherwise fund our corporate initiatives. If we do issue additional equity securities, the issuance may dilute our earnings per share and stockholders' percentage ownership.
Item 1B. Unresolved Staff Comments
Not applicable.
Item 1C. Cybersecurity
Risk Management and Strategy
We employ risk management, mitigation and prevention strategies based on frameworks provided by the National Institute of Standards and Technology (“NIST”) regulation standards, third party cyber service providers, and common industry practices. These frameworks are applied across all network, hardware, software and communication platforms whether the platform is self-hosted or provided as a service. We leverage a Risk Assessment Score (“RAS”) based on these standards against any internal networks, platforms, technologies or initiatives as well as any perimeter or connected partner, vendor or third-party service.
30
Table of Contents
Our cyber posture, policies and in-production procedures are designed and developed to manage and minimize risk, threat, or loss to business processing, business objectives and business assets as well as protecting the integrity, confidentiality and personal identifying information (“PII”) of our employees and partners.
Our security team is intentionally comprised of internal personnel with a range of technical, legal and management disciplines as well as external, third-party cyber service providers, auditors and technical consultants. This allows for broader monitoring, objective reporting, controlled policy, decreased recovery time objectives and quicker incident response.
We maintain cybersecurity risk insurance, conduct threat scenario exercises, provide end user cyber awareness and security training, perform regular vulnerability audits and formally report the relevant results, statuses or assessments to our senior management team or other identified key stakeholders.
Governance
Cybersecurity operations generally fall under the discretion of the IT Director, who has 20 years of experience and is a Certified Secure Infrastructure Specialist (CSIS - Comptia) and IT Operations Specialist (CIOS - Comptia).Our IT Director regularly communicates with and provides relevant cyber reporting, analysis, statistics and statuses to the Chief Financial Officer, who also has a background in IT and is a Certified Information Systems Auditor.
Our Cyber Incident Response Plan employs an operational incident-handling capability that includes preparation, detection, analysis, containment, eradication, recovery, and communication procedures.
Our cyber policies are based on the National Institute of Standards and Technology 800-171 and CMMC Level 2 framework, requiring formal written policies, procedures, plans of action, general security plans and regular audits. In addition, Southland carries Privacy, Security and Technology Insurance covering incidents and responses related to business interruption, data recovery, data breach, extortion and ransomware, and crisis management.
The Company’s cybersecurity program, identified events, current and future strategies are presented to the Audit Committee for periodic review. The Audit Committee may choose to present relevant information to our board of directors (the “Board”) as deemed necessary.
See "Systems and information technology interruption and breaches in data security and/or privacy could adversely impact our ability to operate and negatively impact our results of operations" in “Item 1A. Risk Factors.”
Item 2. Properties
We lease our headquarters in Grapevine, Texas and own and lease other facilities throughout the United States and Canada. Our facilities include permanent and temporary office space, equipment yards, storage yards, maintenance facilities, shops, warehouses, training and education facilities, and other permanent and temporary locations as needed in our business, all of which are used by both our Civil and Transportation segments.
Item 3. Legal Proceedings
Legal proceedings are discussed in Note 17 of the Notes to Consolidated Financial Statements and are incorporated herein by reference.
Item 4. Mine Safety Disclosures
Not applicable.
31
Table of Contents
PART II
Item 5. Market for Registrant's Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities
Market Information
Our Common Stock, and Warrants are publicly traded on the NYSE American LLC under the symbols “SLND” and “SLND WS”, respectively.
Holders
As of February 24, 2025, we had 53,987,069 shares of Common Stock issued and outstanding held of record by 2,172 holders. Such numbers do not include Depository Trust Company participants or beneficial owners holding shares through nominee names.
Dividends
We have not paid any cash dividends on our Common Stock to date. We may retain future earnings, if any, for future operations, expansion and debt repayment and have no current plans to pay cash dividends for the foreseeable future. Any decision to declare and pay dividends in the future will be made at the discretion of the Board and will depend on, among other things, our results of operations, financial condition, cash requirements, contractual restrictions and other factors that the Board may deem relevant. In addition, our ability to pay dividends may be limited by covenants of any existing and future outstanding indebtedness we incur. We do not anticipate declaring any cash dividends to holders of Common Stock in the foreseeable future.
Item 6. Reserved
Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations
References to the “Company,” “our,” “us,” “we,” or “Southland” refer to Southland Holdings, Inc. and its consolidated subsidiaries. The following discussion and analysis contain forward-looking statements relating to future events or our future financial performance, which involve risk and uncertainties. Our actual results could differ materially from those anticipated in these forward-looking statements. Please see the discussion regarding forward-looking statements and certain risks included under the “Cautionary Note Regarding Forward-Looking Statements” and “Item 1A. Risk Factors” sections for a discussion of some of the uncertainties, risks, and assumptions associated with these statements. The following discussion and analysis present information that we believe is relevant to an assessment and understanding of our consolidated balance sheets, statements of cash flows, and results of operations. This information should be read in conjunction with the consolidated financial statements and the notes related thereto which are included in this Annual Report.
Overview
Southland is a diverse leader in specialty infrastructure construction with roots dating back to 1900. The end markets for which we provide services cover a broad spectrum of specialty services within infrastructure construction. We design and construct projects in the bridges, tunnels, communications, transportation and facilities, marine, steel structures, water and wastewater treatment, and water pipelines end markets.
Southland is based in Grapevine, Texas. It is the parent company of Johnson Bros. Corporation, American Bridge Company, Oscar Renda Contracting, Southland Contracting, Mole Constructors, and Heritage Materials. With the combined capabilities of these six primary subsidiaries, Southland has become a diversified industry leader with projects spanning North America in various end markets.
32
Table of Contents
Key Factors Affecting Results of Operations
Business Environment
Our Civil segment primarily operates throughout North America and specializes in services that include the design and construction of water pipeline, pump stations, lift stations, water and wastewater treatment plants, concrete and structural steel, outfall, and tunneling.
Our Transportation segment primarily operates throughout North America and specializes in services that include the design and construction of bridges, roadways, marine, dredging, ship terminals and piers, and specialty structures and facilities. Our Transportation segment is responsible for the construction of bridges and structures including many of the most recognizable bridges, convention centers, sports stadiums, marine facilities, and Ferris wheels in the world.
Both our Civil and Transportation segments continue to identify new opportunities to grow our business, and the future outlook of the end markets we serve remains positive. Although risk and uncertainty exist, including, but not limited to, the items addressed within our forward-looking statements and risk factors, we believe that we are well positioned to compete on new infrastructure projects in both the public and private sectors.
Market Trends and Uncertainties
In both our Transportation and Civil segments, we have competitors within the individual markets and geographic areas in which we operate, ranging from small, local companies to larger regional, national, and international companies. Although the construction business is highly competitive, there are few, if any, companies which compete in all of our market areas, both geographically and from an end market perspective. The degree and type of competition is influenced by the type and scope of construction projects within individual markets. Equipment ownership and ability to self-perform across numerous disciplines are two of our significant competitive advantages. We believe that the primary factors influencing competition in our industry are price, reputation for quality, safety, schedule certainty, relevant experience, availability of field supervision and skilled labor, machinery and equipment, financial strength, as well as knowledge of local markets and conditions.
Many of our competitors have the ability to perform work in either the private or public sectors. When opportunities for work in one sector are reduced, competitors tend to look for opportunities in the other sector. This migration has the potential to reduce revenue growth and/or increase pressure on gross profit margins.
We have seen an increase in demand for specialty construction projects in recent years at the federal, state, and local level. We anticipate the further spending on infrastructure related to economic stimulus spending including the Infrastructure Investment and Jobs Act that was passed on 2021, and other federal, state, or local initiatives.
We believe that the combination of our experience, reputation, and technical expertise are unmatched among companies of our size. This combination of skills has allowed us to pursue complex projects with fewer competitors.
Seasonality, Cyclicality, and Variability
The results of our operations are subject to quarterly variations. Much of the variation is the result of weather, particularly rain, ice, snow, heat, wind, and named storms, which can impact our ability to perform construction activities. These weather impacts can affect revenue and profitability in either of our business segments. Any quarter can be affected either negatively or positively by atypical weather patterns in any part of North America, or other areas in which we operate. Traditionally, our first quarter is the most weather-affected; however, this may or may not necessarily be true in future periods.
Our business may also be affected by overall economic market conditions, including but not limited to declines in spending by project owners, delays in new projects, by changes in client schedules, or for other reasons.
33
Table of Contents
Critical Accounting Policies and Estimates
The preparation of consolidated financial statements in conformity with the accounting principles generally accepted in the United States (“GAAP”) requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and the disclosure of contingent liabilities as of the date of the financial statements and the reported amounts of revenues and expenses earned and incurred, respectively, during the reporting period. Critical accounting estimates are fundamental to the portrayal of both our financial condition and results of operations and often require difficult, subjective, and complex estimates and judgments by management. We evaluate our estimates and assumptions on an ongoing basis using historical experience and other factors, including the current economic environment, which we believe to be reasonable under the circumstances. We adjust such estimates and assumptions when facts and circumstances dictate. As future events and their effects cannot be determined with precision, actual results could differ significantly from these estimates. Changes in these estimates will be reflected in the consolidated financial statements in future periods. The following discussion addresses the items we have identified as our critical accounting estimates.
Revenue Recognition
We recognize revenue over time as we satisfy our performance obligations. We generally use an input method measured by comparing actual costs incurred to date to total estimated costs for the project to recognize revenue as it is the best available method to recognize the progress of satisfying our performance obligations and transfer of control to our customers.
Due to the nature of our industry the use of this method requires us to make material estimates and assumptions that are subject to a high degree of uncertainty. To determine estimated transaction price and estimated cost at completion we rely on our experience, and outside expert opinions on an as needed basis, with particular types of projects and customers using information that is reasonably available to us.
An estimated transaction price can be impacted by numerous items related to variable consideration, including but not limited to: claims, approved and pending changes orders, unpriced change orders, completion incentives, liquidated damages, penalties, and other contractual provisions. An estimated cost at completion may fluctuate based on numerous items, including but not limited to:
● Complexity in original design,
● Owner-directed changes,
● Differing site conditions,
● Productivity,
● Availability and cost of labor, equipment, or materials,
● Weather,
● Changes in technology,
● Governmental or environmental restrictions,
● Subcontractor and joint venture partner performance,
● Expected and unexpected cost of warranties,
● Insurance, legal, and consultant costs, and
● Time to recover, or not recover, additional contract costs.
34
Table of Contents
We recognize the impact of any changes in estimated transaction price or estimated cost at completion on a cumulative catch-up basis. This can result in the recognition of revenue in a current period related to the satisfaction of performance obligations that occurred or partially occurred in a prior period. This can also result in the reversal of revenue recognized in a prior period, in the current period. If it is estimated that a project will have costs in excess of expected revenues, we recognize the full loss in that period and any adjustments to that expected loss in the period in which that change in expected loss may be identified.
Accounting for Warrants
The Company accounts for warrants as either equity-classified or liability-classified instruments based on an assessment of the instruments’ specific terms and applicable authoritative guidance in FASB ASC 480, “Distinguishing Liabilities from Equity” (“ASC 480”), and ASC 815, “Derivatives and Hedging” (“ASC 815”). The assessment considers whether the instruments are freestanding financial instruments pursuant to ASC 480, meet the definition of a liability pursuant to ASC 480, and whether the instruments meet all of the requirements for equity classification under ASC 815, including whether the instruments are indexed to the Company’s own Common Stock and whether the instrument holders could potentially require “net cash settlement” in a circumstance outside of the Company’s control, among other conditions for equity classification. This assessment, which requires the use of professional judgment, was conducted at the time of warrant issuance and as of each subsequent quarterly period end date while the instruments are outstanding. The Company has concluded that the Public Warrants and Private Warrants issued pursuant to the warrant agreement qualify for equity accounting treatment.
Recent Events
See section titled "Basis of Presentation” discussing the consummation of the Merger.
In December 2024, the Company agreed to issue an aggregate of 5,830,899 shares of common stock (the “Shares”), par value $0.0001 per share, in exchange for the full satisfaction and discharge of an aggregate of $20.0 million in outstanding amounts under certain promissory notes held by Frank Renda, Rudy Renda and Tim Winn (the “Transaction”) with a price per share of $3.43, calculated using the greater of (a) the volume-weighted average price per share of Common Stock, rounded to the nearest hundredth of a cent, on NYSE for the thirty consecutive trading days immediately preceding and ending on December 27, 2024 and (b) the closing price of Common Stock on NYSE on December 27, 2024. The $20.0 million conversion to shares of common stock was comprised of $13.2 million of secured notes and accrued interest thereupon along with $6.8 million of certain promissory notes and accrued interest thereupon. The Transaction was approved by the Company’s Audit Committee and Board of Directors.
In the second quarter of 2023, Southland decided to discontinue certain types of projects in its Materials & Paving business line (“M&P”) and sold assets related to producing large scale concrete and asphalt. M&P is reported in the Transportation segment. In an effort to wind down this component of its Transportation segment and reallocate resources towards core operations, the Company sold various materials production assets. As a result, the Company recorded unfavorable charges during the year ended December 31, 2023 related to additional expected future costs associated with procuring and transporting materials from third parties. Southland recorded the increased estimated future costs to finish these projects during the year ended December 31, 2023, in accordance with GAAP. The Company has concluded this action with M&P does not qualify for Discontinued Operations treatment and presentation under ASC 205-20 as it does not represent a strategic shift in the Company’s business.
For the year ended December 31, 2024, M&P contributed $100.6 million to revenue and $83.1 million in gross loss. See the Transportation portion of the Segment Results section of this Item 7. “Management’s Discussion and Analysis of Financial Condition and Results of Operations” for additional information. This compares to the $188.3 million to revenue and $86.6 million to gross loss for the year ended December 31, 2023. As of December 31, 2024, approximately 6.3% of Southland’s Backlog was in M&P, and Southland estimates most of the active scope of this work to be substantially completed in the next twelve months.
35
Table of Contents
Results of Operations
Comparisons of the Year Ended December 31, 2024 to the Year Ended December 31, 2023
The following table sets forth our consolidated statements of operations for the years ended December 31, 2024 and December 31, 2023:
Selling, general, and administrative expenses 63,274 67,195
Gain (loss) on investments, net (225) 30
Net income (loss) attributable to noncontrolling interests (163) 538
Net loss attributable to Southland Stockholders $ (105,365) $ (19,253)
Revenue
Revenue for the year ended December 31, 2024, was $980.2 million, a decrease of $180.2 million, or 15.5%, compared to the year ended December 31, 2023. The decrease was attributable to a $166.0 million decrease in revenue in our Transportation segment primarily due to impacts related to exiting the M&P business line and a $14.2 million decrease in our Civil segment primarily due to projects that were substantially completed in 2023 compared to 2024, which was partially offset by new projects started in 2024.
Cost of construction
Cost of construction for the year ended December 31, 2024, was $1,043.2 million, a decrease of $81.4 million, or 7.2%, compared to the year ended December 31, 2023. The decrease was comprised of a $102.1 million decrease in our Transportation segment due to impacts related to exiting the M&P business line and more projects nearing substantial completion in 2024 compared to 2023, and a $20.7 million increase in our Civil segment due to new projects started in 2024, partially offset by projects that were substantially completed in 2023 compared to 2024.
Gross profit (loss)
Gross loss for the year ended December 31, 2024, was $63.0 million, an increase of $98.9 million, or 276.0%, compared to the year ended December 31, 2023. The increase was primarily due to project delays and increases in the cost of materials which led to a $63.9 million increase in gross loss in our Transportation segment and a $35.0 million decrease in gross profit in our Civil segment.
Selling, general, and administrative costs
Selling, general, and administrative costs for the year ended December 31, 2024, were $63.3 million, a decrease of $3.9 million, or 5.8%, compared to the year ended December 31, 2023. The decrease was primarily driven by a $5.2 million decrease in compensation offset by a $1.4 million increase in professional fees.
Other income, net
Other income, net for the year ended December 31, 2024 was $3.6 million, a decrease of $19.9 million, or 84.6%, compared to the year ended December 31, 2023. The decrease was primarily driven by a reversal of a non-cash contingent liability in 2023 due to changes in the likelihood of earnout shares being issued based on 2023 performance.
36
Table of Contents
Interest expense
Interest expense for the year ended December 31, 2024, was $29.5 million, an increase of $10.0 million, or 51.6%, compared to the year ended December 31, 2023. The increase is primarily driven by an increase in external borrowings compared to the prior year and higher interest rates on the additional borrowings.
Income tax benefit
Income tax benefit for the year ended December 31, 2024, was $46.9 million or an effective tax rate of 30.8%. The primary differences from the federal statutory rate of 21% were (i) state income tax benefit of $7.6 million, (ii) the benefit of foreign tax rate differences of $13.2 million due to operations in jurisdictions like Canada and the Bahamas, (iii) the expense recorded for the valuation allowance against the net deferred tax assets for Johnson Bros. Corporation’s separate state filings and Southland Mole of Canada, and (iv) the benefit of the release of uncertain tax position liability previously recorded for American Bridge federal NOL and depreciation matters prior to 2020 tax year.
Income tax benefit for the year ended December 31, 2023, was $8.5 million, or an effective rate of 31.3%. The primary differences from the federal statutory rate of 21% were (i) the revocation of Subchapter S-corporation status by Southland Holdings, LLC and its Qualified Subchapter S Subsidiary group of entities inclusive of Southland Contracting, Johnson Bros., Mole Constructors, Heritage Materials, and Southland RE Properties of $4.8 million, (ii) the benefit from the change in valuation allowance of $3.2 million primarily due to the change in domestic filing structure and the subsequent removal of the valuation allowance on American Bridge domestic deferred tax assets, (iii) the benefit from foreign tax rate differences of $5.5 million due to operations in jurisdictions like Canada and the Bahamas with different effective tax rates, and (iv) the permanent inclusion difference of foreign income through Section 951A Global Intangible Low-Taxed Income (GILTI) of $8.2 million net of related deduction.
On August 16, 2022, the Inflation Reduction Act (“IRA”) was enacted in the United States. Among other provisions, the IRA included a new 15% Corporate Alternative Minimum Tax (“CAMT”) for corporations with financial income in excess of $1 billion and a 1% excise tax on corporate share repurchases. The CAMT is effective for tax years beginning on or after January 1, 2023. As of December 31, 2024, the excise tax on corporate share repurchases is not expected to impact the Company as the Company has no plans for repurchases in the coming year.
On December 14, 2023, the FASB issued ASU 2023-09 which established new income tax disclosure requirements. Public business entities must apply the guidance to annual periods beginning after December 15, 2024. This standard has not been elected for early adoption this period but will be implemented for the next annual period, as required. We are currently evaluating the impact ASU 2023-09 will have on our consolidated financial statements and related disclosures.
Segment Results
Year Ended
% of Total % of Total