ORN · Read the filing

Item 1A. RISK FACTORS

We operate in a changing environment that involves numerous known and unknown risks and uncertainties that could materially adversely affect our business, financial condition, and results of operations. The risks described below highlight the known factors that have affected and could affect us in the future. We may also be affected by unknown risks or risks that we currently think are immaterial. If any such events actually occur, our business, financial condition, and results of operations could be materially adversely affected.

Risk Factors Relating to Our Business

We may be unable to obtain sufficient bonding capacity for our contracts and the need for performance and surety bonds may adversely affect our business.

As more fully described in “Insurance and bonding” under “Item 1. Business,” we are generally required to post bonds or other security in connection with government and certain private sector contracts to ensure job completion. We have entered into bonding agreements with several large multinational surety companies, which act as surety, issue bid bonds, performance bonds and payment bonds, and obligate themselves upon other contracts of guaranty required by us in the day-to-day operations of our business. However, our sureties are not obligated under the bonding agreements to issue bonds for us, and bonding decisions are made on a case-by-case basis. We are bidding on increasingly complex, larger jobs for customers who require significant bonds. We may not be able to maintain a sufficient level of bonding capacity in the future which could preclude us from being able to bid for certain contracts and successfully contract with certain customers. In addition, the conditions of the bonding market may change, increasing our costs of bonding or restricting our ability to get new bonding, which could have a material adverse effect on our business, operating results and financial condition.

We rely on highly competitive and highly regulated government contracts.

Government funding for public works projects is limited, thus creating a highly competitive environment for the limited number of public projects available. Reduced levels of, or delays in, government funding cause delays in project lettings and result in intense competition and pricing pressure for such projects. In addition, government contracts are subject to specific procurement regulations, contract provisions and a variety of regulatory requirements relating to their formation,

Table of Contents

administration, performance and accounting. Many of these contracts include express or implied certifications of compliance with applicable laws and contract provisions. Any violations of these regulations could bring about litigation, including the possibility of qui tam (“whistleblower”) litigation brought by private individuals on behalf of the government under the Federal Civil False Claims Act, and could cause termination of other existing government contracts and result in the loss of future government contracts. Due to the significant competition in the marketplace and the level of regulations on government contracts, we could suffer reductions in new projects and see lower revenues and profit margins on those projects, which could have a material adverse effect on our business, operating results and financial condition.

Our operations are susceptible to a variety of adverse conditions including weather conditions, natural disasters, health epidemics or pandemics or other contagious outbreaks and terrorist attacks that could negatively impact the markets in which we operate.

Our business, operating results and financial condition could be materially and adversely affected by severe weather and other natural disasters, such as earthquakes, flooding or hurricanes, particularly along the Gulf Coast, the West Coast, the Atlantic Seaboard, and the Caribbean Basin. Repercussions of severe weather conditions could cause significant interruption of projects in process and have safety implications to personnel at those sites.

Our business, operating results and financial condition could be materially and adversely affected if a public health epidemic or pandemic or other contagious outbreak interferes with our ability, or that of our employees, contractors, suppliers, customers and other business partners to perform our and their respective responsibilities and obligations relative to the conduct of our business.

Terrorist attacks, targeted at ports, marine facilities, shipping or metropolitan areas could affect the markets in which we operate our business and our expectations. Increased armed hostilities, terrorist attacks or responses from the United States may lead to further acts of terrorism and civil disturbances in the United States or elsewhere, which may further contribute to economic instability in the United States. These attacks or armed conflicts may affect our operations or those of our customers or suppliers and could impact our revenues, our production capability and our ability to complete contracts in a timely manner.

Demand for our services may decrease due to economic recession or a reduction of demand in end markets of our customers.

Our concrete segment depends on continued growth in population in our geographic market areas in Texas and most recently in Florida to support commercial development. A growing population generates economic growth and expansion. If the population decreases or slows in growth, it may adversely affect economic growth and ultimately limit the need for construction services in the areas we currently perform services.

Moreover, even when the underlying economic fundamentals that ordinarily drive the level of construction activity are strong, the level of economic activity in such markets may be suppressed.

Our marine segment depends on continued investment in and scheduled funding of port and marine infrastructure by federal, state, and local governmental authorities, as well as privately owned companies, which in turn may depend upon demand for marine vessels, including cruise ships and cargo ships, and other port-related activities. If funding is diverted from port and marine infrastructure, including due to a reduced demand in the vessels to be serviced at those facilities, the demand for services within our marine segment may decrease.

Table of Contents

Fluctuations in commodity prices or interest rates may affect our customers’ investment decisions and therefore subject us to risks of cancellation, delays in existing work, or changes in the timing and funding of new awards. Additionally, fluctuations in commodity prices can negatively affect our project costs.

Interest rates may affect the cost of financing for our customers’ capital projects and investments. These increased costs may affect their capacity and willingness to undertake new investments, and may result in the delay or cancellation of projects they would otherwise undertake.

Commodity prices can affect our customers in a number of ways. For example, for those customers that produce commodity products such as oil, gas, concrete, or steel products, fluctuations in price can have a direct effect on their profitability and cash flow and, therefore, their willingness to continue to invest or make new capital investments. To the extent commodity prices decline or fluctuate and our customers defer new investments or cancel or delay existing projects, the demand for our services decreases, which may have a material adverse impact on our business, financial condition, and results of operations.

Commodity prices can also strongly affect the costs of projects. We use concrete and steel as well as diesel fuel and other petroleum-based products to operate our equipment used in our construction contracts. Fluctuations in supplies relative to demand and other factors can cause unanticipated increases in their cost. Rising commodity prices can negatively impact the potential returns on projects that are planned, as well as those in progress, and result in customers deferring new investments or canceling or delaying existing projects. The short-term nature of the majority of our projects typically protects us from these potential price increases, however, if we are unable to procure commodities for completion of our projects at estimated prices due to rising commodity prices, our margins may erode on certain in progress or future projects.

Our business depends on good customer relationships and our reputation in both the marine and concrete infrastructure markets, which is developed and maintained by our executives and key project managers. Loss of any of our relationships, reputation or executives or key project managers could materially reduce our revenues and profits.

Although we have master service agreements with numerous customers that generally define the contractual terms under which we would perform awarded work, contractual commitments are typically entered into on a project-by-project basis, so we generally do not have continuing contractual commitments with our customers beyond the terms of the current contract. We benefit from key customer relationships built over time and with both public and private entities. We also benefit from our reputation in the marine and concrete construction markets developed over years of successfully performing on projects. Both of these aspects of our business were developed and are maintained by our executives and key project managers. Our inability to retain our executives and key project managers or inability to complete projects timely and successfully resulting in customer satisfaction could have a material adverse effect on our current customer relationships and reputation. The inability to maintain relationships with our customers in general or obtain new customers based on our reputation could have a material adverse effect on our business, operating results and financial condition.

We may not be able to fully realize the revenue value reported in our backlog.

As of December 31, 2025, we had a backlog of work to be completed on contracts totaling approximately $480 million in our marine segment and approximately $160 million in our concrete segment. Backlog includes new awards, which represent the potential revenue value realizable pursuant to new project commitments received by us during a given period.

Backlog consists of awarded projects that have either (a) not yet been started or (b) are in progress but are not yet complete. In the latter case, the revenue value reported in backlog is the remaining value related to work that has not yet been completed. We cannot guarantee that the revenue projected in our backlog will be realized, or if realized, will result in earnings. From time-to-time, projects are cancelled that appeared to have a high certainty of going forward at the time they were recorded as new awards. In the event of a project cancellation, we may be reimbursed for certain costs but typically have no contractual right to recover the total revenue reflected in our backlog. In addition to being unable to recover certain direct costs, cancelled projects may also result in additional unrecoverable costs due to the resulting under-utilization of our assets or labor force.

Table of Contents

We could suffer contract losses if we fail to accurately estimate our costs or fail to execute within our cost estimates on fixed-price, lump-sum contracts.

Much of our revenue is derived from fixed-price, lump-sum contracts. Under these contracts, we perform our services and execute our projects at a fixed price and where, as a result, we could benefit from cost savings, but we may be unable to recover any cost overruns. Fixed-price contracts carry inherent risks, including risks of losses from underestimating costs, operational difficulties and other factors that may occur over the contract period. If our cost estimates for a contract areinaccurate, or if we do not execute the contract within our cost estimates, we may incur losses or the project may not be as profitable as we expected. In addition, we are sometimes required to incur costs in connection with modifications to a contract (change orders) that may not be approved by the customer as to scope and/or price, or to incur unanticipated costs, including costs for customer-caused delays, errors in specifications or designs, or contract suspension or termination that we may not be able to recover. These, in turn, could have a material adverse effect on our business, operating results and financial condition. The revenue, cost and gross profit realized on such contracts can vary, sometimes substantially, from the original projections due to changes in a variety of factors, such as:

● project modifications creating unanticipated costs;

● differing site conditions;

● changes in the costs of equipment, materials, labor or subcontractors;

● our suppliers’ or subcontractors’ failure to perform;

● changes in local laws and regulations;

● changes in ad valorem and other tariffs;

● delays caused by local weather conditions; and

These risks may increase if the project is of a long-term duration because of the elevated risk that the circumstances that we based our original bid will change in a manner that increases costs. In addition, we sometimes bear the risk of delays caused by unexpected conditions or events.

We could suffer penalties on our contracts for late completion.

In many instances, including in our fixed-price contracts, we guarantee that we will complete a project by a scheduled date. If we subsequently fail to complete the project as scheduled, without sufficient justification, we may be liable for any customer losses resulting from such delay, generally in the form of contractually agreed-upon liquidated damages. In addition, failure to maintain a required schedule could cause us to default on our government contracts, giving rise to a variety of potential damages. To the extent that these events occur, the total costs of the project could exceed our original estimates, and we could experience reduced profits or, in some cases, a loss for that project.

Our projects could be hindered due to our dependence on third parties to complete many of our contracts.

A portion of the work performed under our contracts is performed by third-party subcontractors we hire. We also rely on third-party equipment manufacturers or suppliers to provide much of the materials used for projects. If we are unable to hire qualified subcontractors or find qualified equipment manufacturers or suppliers, our ability to successfully complete a project could be impaired. If we are not able to locate or engage qualified third-party subcontractors or the amount we are required to pay for subcontractors or equipment and supplies exceeds what we have estimated, especially in a lump-sum or a fixed-price contract, we may suffer losses on these contracts. If a subcontractor, supplier, or manufacturer fails to provide services, supplies or equipment as required under a contract for any reason, we may be required to source these services, equipment or supplies to other third parties on a delayed basis or on less favorable terms, which could impact contract profitability. There is a risk that we may have disputes with our subcontractors relating to, among other things, the quality and timeliness of work performed, customer concerns about the subcontractor, or our failure to extend existing

Table of Contents

task orders or issue new task orders under a contract. In addition, faulty workmanship, equipment or materials could impact the overall project, resulting in claims against us for failure to meet required project specifications.

We may incur higher costs to acquire, manufacture and maintain equipment necessary for our operations.

We do not bid on contracts for which we do not have, or cannot quickly procure, whether through construction, acquisition or lease, the necessary equipment to complete projects. We are capable of building much of the specialized equipment used in our projects, including dayboats, tenders and dredges. To the extent that we are unable to buy or build equipment necessary for our needs, either due to a lack of available funding or equipment shortages in the marketplace, we may be forced to rent equipment on a short-term basis, which could increase the costs of completing contracts, thereby reducing contract profitability. In addition, our equipment requires continuous maintenance, which we primarily provide through our own repair facilities, as well as certification by the U.S. Coast Guard for certain marine segment assets. If we are unable to continue to maintain the equipment in our fleet or are unable to obtain the requisite certifications, we may be forced to obtain third-party repair services, be unable to use our uncertified equipment or be unable to bid on contracts, which could have a material adverse effect on our business, operating results and financial condition.

In addition, our vessels in the marine segment may be subject to arrest or seizure by claimants as security for maritime torts committed by the vessel or us, a breach of a fleet mortgage secured by the vessel, or the failure by us to pay for necessities, including fuel and repair services, which were furnished to the vessel. Such arrest or seizure could preclude the vessel from working, thereby causing delays in marine segment projects.

Our business is subject to significant operating risks and hazards that could result in damage or destruction to property, injuries or loss of life, which could result in losses or liabilities to us.

Construction and maintenance sites are potentially dangerous workplaces and often put our employees and others in close proximity with mechanized equipment, moving vehicles, or other construction or worksite hazards. On most sites, we are responsible for safety and are contractually obligated to implement safety procedures. Our safety record is an important consideration for us and for our customers. If serious accidents or fatalities occur or our safety record deteriorates, we may be excluded from bidding on certain work, expose ourselves to possible lawsuits, and existing service arrangements could be terminated, thus having a material adverse impact on our financial position, results of operations, cash flows and liquidity. Further, regulatory changes implemented by OSHA or the U.S. Coast Guard could impose additional costs on us. Adverse experience with hazards and claims could have a negative effect on our reputation with our existing or potential new customers and our prospects for future work.

The businesses of marine infrastructure construction, port maintenance, dredging and salvage are generally subject to a number of risks and hazards, including environmental hazards, industrial accidents, hurricanes, adverse weather conditions, collisions with fixed objects, cave-ins, encountering unusual or unexpected geological formations, disruption of transportation services and flooding. These risks could result in damage to, destruction or loss of, dredges, transportation vessels, other maritime structures and buildings, and could also result in personal injury or death, environmental damage, performance delays, monetary losses or legal liability.

In the concrete segment, our workers are subject to the usual hazards associated with providing construction and related services on construction sites including environmental hazards, industrial accidents, hurricanes, adverse weather conditions, and flooding. Operating hazards can cause personal injury or death, damage to or destruction of property, plant and equipment, environmental damage, performance delays, monetary losses or legal liability.

Our marine segment operates in jurisdictions outside of the U.S. and we intend to continue expanding our operations to more jurisdictions outside of the U.S.

Our marine segment, which accounted for 63.9%, 65.5% and 55.6% of our contract revenues for the years ended December 31, 2025, 2024 and 2023, respectively, has a significant portion of those operations performed outside of the U.S. For the years ended December 31, 2025, 2024 and 2023, our international operations generated approximately 4.9%, 7.4% and 5.1% of our contract revenues, respectively. The Bahamas represented our largest international market outside of the U.S., with our Bahamian operations representing 4.9% and 7.4% of our contract revenues for the year ended December 31, 2025 and 2024, respectively, including 14.2% and 1.8% of our unrestricted total cash balance at December 31, 2025 and 2024,

Table of Contents

respectively. In addition, we intend to expand our operations to other areas outside the U.S. in the future. International operations are subject to a number of risks and uncertainties that could negatively impact our results from operations, including:

● expropriation or nationalization of assets;

● our inexperience in certain international markets;

● health emergencies or pandemics;

● fluctuations in foreign currency exchange rates;

● political and economic instability; and

● wars, rebellions and acts of terrorism.

Our current insurance coverage may not be adequate, and we may not be able to obtain insurance at acceptable rates, or at all.

We maintain various insurance policies, including general liability and workers’ compensation. We are partially self-insured under some of our policies, and our insurance does not cover all types or amounts of liabilities. We are not required to, and do not, specifically set aside funds for our self-insurance programs.

At any given time, we are subject to multiple workers’ compensation and personal injury claims. We maintain substantial loss accruals for workers’ compensation claims, and, until recently, our workers’ compensation and insurance costs have been rising for several years notwithstanding our emphasis on safety. Our insurance policies may not be adequate to protect us from liabilities that we incur in our business. In addition, some of the projects that we bid on require us to maintain high levels of builder’s risk insurance. We may not be able to obtain similar levels of insurance on reasonable terms, or at all. Our inability to obtain such insurance coverage at acceptable rates or at all could have a material adverse effect on our business, operating results and financial condition.

Furthermore, due to a variety of factors such as increases in claims, the rise of “nuclear verdicts” in some of the jurisdictions in which we operate and projected significant increases in medical costs, our insurance premiums may increase in the future and we may not be able to obtain similar levels of insurance on reasonable terms, or at all. Any such inadequacy of, or inability to obtain, insurance coverage at acceptable rates, or at all, could have a material adverse effect on our business, operating results and financial condition.

Insurance liabilities are difficult to assess and quantify due to unknown factors, including the severity of an injury, the determination of our liability in proportion to other parties, the number of incidents not reported and the effectiveness of our safety program. If we were to experience insurance claims or costs above our estimates, we might be required to use working capital to satisfy these costs rather than to maintain or expand our operations. To the extent that we experience a material increase in the frequency or severity of accidents or workers’ compensation and health claims, or unfavorable developments on existing claims, our operating results and financial condition could be materially and adversely affected.

Table of Contents

Our operations are subject to environmental laws and regulations that may expose us to significant costs and liabilities.

Our marine infrastructure construction, salvage, demolition, dredging and dredge material disposal activities are subject to stringent and complex federal, state and local environmental laws and regulations, including those concerning air emissions, water quality, solid waste management, and protection of certain marine and bird species, their habitats, and wetlands. We may incur substantial costs in order to conduct our operations in compliance with these laws and regulations. For instance, we may be required to obtain, maintain and comply with permits and other approvals (as well as those obtained for projects by our customers) issued by various federal, state and local governmental authorities; limit or prevent releases of materials from our operations in accordance with these permits and approvals; and install pollution control equipment. In addition, compliance with environmental laws and regulations can delay or prevent our performance of a particular project and increase related project costs. Moreover, new, stricter environmental laws, regulations or enforcement policies, including those imposed in response to climate change, could be implemented that significantly increase our compliance costs, or require us to adopt more costly methods of operation.

Failure to comply with environmental laws and regulations, or the permits issued under them, may result in the assessment of administrative, civil and criminal penalties, the imposition of remedial obligations and the issuance of injunctions limiting or preventing some or all of our operations. In addition, strict joint and several liability may be imposed under certain environmental laws, which could cause us to become liable for the investigation or remediation of environmental contamination that resulted from the conduct of others or from our own actions that were in compliance with all applicable laws at the time those actions were taken. Further, it is possible that we may be exposed to liability due to releases of pollutants, or other environmental impacts that may arise in the course of our operations. For instance, some of the work we perform is in underground and water environments, and if the field location maps or waterway charts supplied to us are not accurate, or if objects are present in the soil or water that are not indicated on the field location maps or waterway charts, our underground and underwater work could strike objects in the soil or the waterway bottom containing pollutants and result in a rupture and discharge of pollutants. In addition, we sometimes perform directional drilling operations below certain environmentally sensitive terrains and water bodies, and due to the inconsistent nature of the terrain and water bodies, it is possible that such directional drilling may cause a surface fracture releasing subsurface materials. These releases may contain contaminants in excess of amounts permitted by law, may expose us to remediation costs and fines and legal actions by private parties seeking damages for non-compliance with environmental laws and regulations or for personal injury or property damage. We may not be able to recover some or any of these costs through insurance or increased revenues, which may have a material adverse effect on our business, operating results and financial condition. See “Item 1. Business – Environmental Matters” for more information.

Our concrete segment is subject to extensive and complex regulations that affect land development and building construction, including zoning, density restrictions, building design and building standards. These regulations often provide broad discretion to the administering governmental authorities as to the conditions we must meet prior to development or construction being approved, if approved at all. We are subject to determinations by these authorities as to the adequacy of water or sewage facilities. New building developments may also be subject to various assessments for schools and other public improvements. In addition, in many markets, government authorities have implemented no growth or growth control initiatives. Any of these can limit, delay or increase the costs of development and construction.

The anticipated investment in port and marine infrastructure may not be as large as expected, which may result in periods of low demand for our marine construction services.

The demand for port construction, maintenance infrastructure services and dredging may be vulnerable to downturns in the economy generally and in the marine transportation industry specifically. The amount of capital expenditures on port facilities and marine infrastructure in our markets is affected by the actual and anticipated shipping and vessel needs of the economy in general and in our geographic markets in particular. If the general level of economic activity deteriorates, our customers may delay or cancel expansions, upgrades, maintenance and repairs to their infrastructure. A number of other factors, including the financial condition of the shipping industry, could adversely affect our customers and their ability or willingness to fund capital expenditures in the future. During downturns in the U.S. or world economies, the anticipated port usage in our geographic markets may decline, resulting in less port construction, upgrading and maintenance. As a result, demand for our services could substantially decline for extended periods.

Table of Contents

Restrictions on foreign ownership of our vessels could limit our ability to sell off any portion of our marine construction segment or result in the forfeiture of our vessels or in our inability to continue our operations in United States navigable waters.

The Foreign Dredge Act of 1906, the Merchant Marine Act of 1920 (the “Jones Act”) and the Vessel Documentation Act require vessels engaged in thetransportofmerchandiseorpassengersbetweentwopointsintheUnitedStatesordredginginthenavigablewatersof the United States to be owned and controlled by United States citizens. The United States citizen ownership and control standards require the vessel-owning entity to be at least 75% U.S. citizen-owned, thus restricting foreign ownership interests in the entities that directly or indirectly own the coastwise-qualified vessels we operate. If we were to seek to sell any portion of our marine segment that owns any of these vessels, we may have fewer potential purchasers, since some potential purchasers might be unable or unwilling to satisfy the foreign ownership restrictions described above; additionally, any sales of certain of our larger vessels to foreign buyers would be subject to approval by the U.S. Maritime Administration. As a result, the sales price for that portion of our marine segment may not attain the amount that could be obtained in an unregulatedmarket.

Our concrete segment is geographically concentrated in Texas.

Our concrete segment, which accounted for 36.1%, 34.5% and 44.4% of our contract revenues for the years ended December 31, 2025, 2024 and 2023, respectively, is concentrated in the metropolitan areas of the State of Texas, particularly Houston and Dallas. Given this concentration, general economic conditions, regulatory changes, changes in demographics, material costs, labor conditions, competition and other conditions that affect those metropolitan areas or the State of Texas may have a disproportionate impact on the performance of our concrete segment. In addition, our operations in Texas may make us more susceptible to natural disasters, including hurricanes, tornadoes and flooding.

A significant portion of our revenues may be concentrated among a small number of projects.

From time to time in any given period, a significant percentage of our revenues may be attributable to a limited number of contracts, customers or projects. A reduction in scale, a delay in scheduled work, the completion or termination of a material contract, or the loss of a major customer could negatively impact our reputation and could have an adverse effect on our business, our revenue and results of operations. Furthermore, even if the ultimate amount of our contract revenue attributable to a particular project remains the same, delays in scheduled work may impact the timing of the recognition of our contract revenues and profits. In addition, in many cases, we work as a subcontractor or among a team of contractors. Our ability to timely execute on our work is often affected by scheduling changes or contract performance by our co-contractors, all of which are outside of our control.

For example, our Pearl Harbor Project for the United States Navy, our portion of which totals approximately $463.9 million, and our design-build contract for the Grand Bahama Shipyard totaling approximately $125.9 million may concentrate our revenues. To the extent we are unable to perform our services or experience any delays in the Pearl Harbor Project, the Grand Bahama Shipyard or any other significant project, anticipated revenue or profits associated with that project may not be realized or may otherwise shift into future periods, which may impact the accuracy of our guidance. Furthermore, if we are unable to replace projects like the Pearl Harbor Project or the Grand Bahama Shipyard upon completion of those projects, our revenue and profitability may be lower in future years.

The timing and funding of new contracts may result in volatility in our cash flow and profitability. These factors, as well as others that may cause our actual financial results to vary from any publicly disclosed earnings guidance and forecasts, are outside of our control.

Our revenues are generated from project-based work. It is generally very difficult to predict the timing and source of awarded contracts, and the timing of revenue under awarded contracts. The selection of, timing of, or failure to obtain projects, delays in awards of projects, the rebidding or termination of projects due to budget overruns, or the cancellations of projects or delays in completion of contracts could result in the under-utilization of our assets and reduce our cash flows and profitability, or cause revenues to be shifted further into the future. Even if we are awarded contracts, we face additional risks that could affect whether, or when, work will begin. For example, some of our contracts are subject to financing and other contingencies that may delay or result in termination of projects. This may make it difficult to match

Table of Contents

workforce size and equipment location with contract needs. In some cases, we may be required to bear the cost of a readily available workforce and fleet of equipment that is larger than needed at the time, resulting in unpredictability in our cash flow, expenses and profitability. If an expected contract award or the related notice to proceed is delayed or not received, we could incur substantial costs without receipt of any corresponding revenues, or the revenues could appear in periods later than expected. Delays by our customers in obtaining required approvals and permits for their infrastructure projects may delay their awarding contracts for those projects and once awarded, the ability to commence construction under those contracts. Moreover, construction projects for which our services are contracted may require significant expenditures by us prior to receipt of relevant payments by a customer and may expose us to potential credit risk if such customer should encounter financial difficulties. Such expenditures could reduce our cash flows and necessitate increased borrowings under our UMB Credit Agreement (as defined below). In addition, a change in the timing of a construction project may impact future revenue. If a project is delayed, revenue that we expect to receive may appear in periods later than we initially expected, which may impact the accuracy of our guidance. Finally, the winding down or completion of work on significant projects that were active in previous periods will reduce our revenue and earnings if such significant projects have not been replaced in the current period. From time to time, we may publicly provide earnings or other forms of guidance, which reflect our predictions about future revenue, operating costs and capital structure, among other factors. Any such predictions may be impacted by these factors as well as others that are beyond our control and might not turn out to be accurate.

We may not be able to enter into contracts associated with our pipeline of opportunities, or realize any revenue associated with our pipeline of opportunities.

As of December 31, 2025, we had a pipeline of opportunities of approximately $22 billion. We define our pipeline of opportunities as specific projects that we have identified and are tracking as projects of interest.

Our pipeline of opportunities does not represent binding contracts with third parties. Before we can capitalize on our pipeline of opportunities, we would have to enter into contracts with third parties, or otherwise be selected to perform services, for the particular project identified in our pipeline of opportunities. We cannot provide any assurance that we will ultimately enter into a contract with a third party or provide services with respect to any particular opportunity. We may be unable to enter into contracts or perform services associated with an opportunity for a variety of reasons, including being outbid, not having the ability to satisfy customer or contract requirements, resource constraints, or bonding requirements. Even if we enter into a contract associated with an opportunity, it may be for a contract amount that is lower than the amount we estimated and included in our pipeline.

Furthermore, even if we are ultimately awarded contracts in our pipeline of opportunities, we cannot guarantee that the revenue associated with those projects will be realized, or if realized, will result in positive earnings. Further, such contracts would become subject to the typical risks associated with our projects, such as execution risk, counter-party risk, delays, cancellations, cost-overruns, weather conditions, natural disasters, health epidemics, and cybersecurity incidents, among others.

We conduct a portion of our operations through joint ventures, exposing us to risks and uncertainties, many of which are outside of our control.

We conduct a portion of our operations through project-specific joint ventures, pursuant to which we jointly bid on and execute projects with other companies in the construction industry. For example, we are a joint venture partner to Kraemer North America for the Deschutes Estuary Restoration Project. We may in the future enter into additional joint ventures.

These joint ventures expose us to risks and uncertainties. Success on joint venture projects depends in part on whether our joint venture partners satisfy their obligations, and we cannot control the actions of our joint venture partners. Differences in views among joint venture partners may result in delayed decisions or failures to agree on major issues. If our joint venture partners, or as a result the joint venture, fails to satisfy its obligations, the customer may terminate the project, which could result in legal liability to us, harm to our reputation and reduce our revenues and profit for a project. If our reputation as a joint venture partner is harmed, it may be difficult for us to enter into new joint venture arrangements which are increasingly required due to the increased size and scale of projects we are bidding on and expect to bid on in the future.

Table of Contents

We and our joint venture partners are also generally jointly and severally liable for all liabilities and obligations of the joint venture. If our partners do not meet their contractual obligations, the joint venture may be unable to adequately perform and deliver its contracted services, requiring us to make additional investments or perform additional services to the customer. While we attempt to mitigate that risk through indemnification and subcontractor arrangements, we could ultimately be liable for both our obligations and those of our partners, which may result in reduced profits, significant losses on the project and a negative impact to our cash flows.

In some joint ventures and similar arrangements, we may not be the controlling member. In these cases, we may have limited control over the actions of the joint venture. In addition, joint ventures or similar arrangements may not be subject to the same requirements regarding internal controls and internal control over financial reporting that we follow. To the extent the controlling member makes decisions that negatively impact the joint venture or arrangement or internal control problems arise within the joint venture or arrangement, it could have a material adverse impact on our business, results of operations, cash flows or financial condition.

Acquisitions and mergers may disrupt our business, and integrating acquired companies may be more difficult, costly, or time-consuming than we expect.

Our growth strategy includes, among other things, acquisitions and vertical integrations. For example, on February 3, 2026, we completed the acquisition of JEM. Our acquisition activities could be material to our business and involve a number of significant risks, including the following:

● losing key employees and customers; and

The economic benefits expected to result from acquisitions might not occur or may be less than we expect. As with any acquisition, there also may be business disruptions that cause us to lose customers. Failure to successfully identify, acquire and integrate businesses could have an adverse effect on our business, operating results and financial condition, and ability to implement our strategy.

Our financial performance will be negatively impacted if we are unable to execute our growth strategy.

Our current growth strategy is to pursue growth through greenfield expansion, acquisitions, vertical integration and diversification. Our ability to grow organically through greenfield expansion depends on our ability to identify, bid upon, win and perform new and additional projects, and we may not be successful in those endeavors. Our ability to grow organically further depends on our ability to recruit and retain qualified personnel, to fund growth at a reasonable cost, access to sufficient capital resources, competitive factors, and changes in laws and regulations. If we grow too quickly, whether organically or through acquisitions, we may be unable to control costs and maintain our operational standards and such growth could materially and adversely affect our financial condition and results of operations.

Table of Contents

Risk Factors Relating to Our Employees

If we fail to attract, retain and engage appropriately qualified employees, including employees in key positions, our operations and profitability may be harmed. In addition, changes in market compensation rates may adversely affect our profitability.

Our performance is highly dependent on attracting, retaining and engaging appropriately qualified employees in our field and corporate offices. Our strategy of offering high-quality services and products for our customers requires a highly trained and engaged workforce. The turnover rate in the specialty construction industry is relatively high, and there is an ongoing need to recruit and train new employees. Factors that affect our ability to maintain sufficient numbers of qualified employees include, for example, employee engagement, our reputation, unemployment rates, competition from other employers, availability of qualified personnel and our ability to offer appropriate compensation and benefit packages. Failure to recruit or retain qualified employees in the future may impair our efficiency and effectiveness and our ability to pursue growth opportunities. In addition, a significant amount of turnover of our executive team or other employees in key positions with specific knowledge relating to us, our operations and our industry may negatively impact our operations.

We operate in a competitive labor market and there is a risk that market increases in compensation and employer-provided benefits could have a material adverse effect on our profitability. We may also be subject to continued market pressure to increase employee hourly wage rates and increased cost pressure on employer-provided benefits. Our need to implement corresponding adjustments within our labor model and compensation and benefit packages could have a material adverse impact to the profitability of our business.

We may be subject to unionization, work stoppages, slowdowns or increased labor costs.

On February 4, 2022, President Biden issued Executive Order 14063, and on December 22, 2023 the Federal Acquisition Regulatory Council issued a final rule (effective January 22, 2024) that generally requires federal agencies, subject to specified exceptions, to include project labor agreement (“PLA”) requirements on certain federal construction projects estimated to cost the U.S. Government at least $35 million (and permits agencies, in certain circumstances, to require PLAs below that threshold). Although aspects of the PLA mandate have been challenged in litigation, including a January 21, 2025 decision of the U.S. Court of Federal Claims in a bid protest context, the rule has not been blocked nationwide, and agencies may continue to include PLA requirements in solicitations. If we (or our subcontractors) are required to enter into a PLA on a federal project, we could incur higher labor and compliance costs, face staffing/subcontracting constraints, or experience labor-related disruptions, which could have a material adverse effect on our business, operating results and financial condition.

Only a small percentage of our marine segment workforce, located in the Pacific Northwest and Alaska, is currently unionized. If at any time, a majority of our employees unionized, it could limit the flexibility of the workforce and could result in demands that might increase our operating expenses and adversely affect our profitability. Each of our different employee groups could unionize at any time and would require separate collective bargaining agreements. If any group of our employees were to unionize and we were unable to agree on the terms of their collective bargaining agreement or we were to experience widespread employee dissatisfaction, we could be subject to work slowdowns or stoppages. In addition, we may be subject to disruptions by organized labor groups protesting our non-union status. Any of these events would be disruptive to our operations and could have a material adverse effect on our business, operating results and financial condition.

Our employees in the marine segment are covered by federal laws that provide seagoing employees remedies for job-related claims in addition to those provided by state laws.

Many of our marine segment employees are covered by federal maritime law, including provisions of the Jones Act, the Longshore and Harbor Workers Compensation Act (“LHWCA”) and the Seaman’s Wage Act. Jones Act laws typically operate to make liability limits established by state workers’ compensation laws inapplicable to these employees and to permit these employees and their representatives to pursue litigation against employers for job-related injuries. For employees that do not qualify for the Jones Act, but are still injured while performing work on or around navigable waters, the LHWCA is a federal law that provides for the payment of compensation, medical care, and vocational rehabilitation services to such employees. Because in some cases we are not protected by the limits imposed by state workers’

Table of Contents

compensation statutes, we have greater exposure for claims made by these employees as compared to employers whose employees are not covered by these provisions.

For example, in the normal course of business, we are a defendant in various personal injury lawsuits. We maintain insurance to cover claims that arise from injuries to our workforce subject to a deductible. During 2025, we recorded $0.7 million of expense for our self-insured portion of these liabilities. We believe our recorded self-insurance reserves represent our best estimate of the outcomes of these claims. Should negative trends persist, we could be negatively impacted in the future.

If we fail to comply with immigration laws, such failure could result in significant liabilities, harm our reputation with our customers and disrupt our operations.

Although we take steps to verify the employment eligibility status of all of our employees, some of our employees may, without our knowledge, be unauthorized workers. Unauthorized workers are subject to deportation and may subject us to fines or penalties and, if any of our workers are found to be unauthorized, we could experience adverse publicity that could make it more difficult to hire and retain qualified employees. Termination of a significant number of unauthorized employees may disrupt our operations, cause temporary increases in our labor costs as we train new employees and result in additional adverse publicity. We could also become subject to fines, penalties and other costs related to claims that we did not fully comply with all recordkeeping obligations of federal and state immigration laws. If we fail to comply with these laws, our operations may be disrupted, and we may be subject to fines or, in extreme cases, criminal sanctions.

In addition, many of our customer contracts specifically require compliance with immigration laws, and, in some cases, our customers’ audit compliance with these laws. Further, several of our customers require that we ensure that our subcontractors comply with these laws with respect to the workers that perform services for them. A failure to comply with these laws or to ensure compliance by our subcontractors could damage our reputation and may cause our customers to cancel contracts with us or to not award future business to us. These factors could adversely affect our operations and financial position.

General Risk Factors

Systems and information technology interruption or failure and data security breaches could adversely impact our ability to operate or expose us to significant financial losses and reputational harm.

We rely heavily on computer information, communications technology and related systems in order to properly operate our business. From time to time, we experience occasional system interruptions and delays. In the event we are unable to regularly deploy software and hardware, effectively upgrade our systems and network infrastructure, and take other steps to maintain or improve the efficiency and efficacy of our systems, the operation of such systems could be interrupted or result in the loss, corruption, or release of data. In addition, our computer and communication systems and operations could be damaged or interrupted by natural disasters, telecommunications failures, power loss, acts of war or terrorism, computer viruses, malicious code, physical or electronic security breaches, intentional or inadvertent user misuse or error, or similar events or disruptions. Any of these or other events could cause interruptions, delays, loss of critical and/or sensitive data or similar effects, which could have a material adverse impact on our business, financial condition, protection of intellectual property, and results of operations, as well as those of our clients.

In addition, we face the threat to our computer systems of unauthorized access, computer hackers, computer viruses, malicious code, organized cyber-attacks and other security problems and system disruptions, including possible unauthorized access to and disclosure of our and our clients’ proprietary or classified information. We rely on industry accepted security measures and technology to securely maintain all confidential and proprietary information on our computer systems, but they may still be vulnerable to these threats. As a result, we may be required to expend significant resources to protect against the threat of these system disruptions and security breaches or to alleviate problems caused by these disruptions and breaches. Any of these events could damage our reputation and have a material adverse effect on our business, financial condition, results of operations and cash flows.

Table of Contents

Adverse changes in tax laws both in the United States and abroad, changes in tax rates or exposure to additional income tax liabilities could have a material adverse effect on our results of operations.

Tax law changes in the U.S. and abroad could increase our effective tax rate, cash taxes, or compliance costs and adversely affect our results. The European Union’s implementation of the Organisation for Economic Co-operation and Development’s Pillar Two 15% global minimum tax regime, and similar measures under consideration in other jurisdictions, could increase our tax expense depending on how and when countries adopt and apply these rules, even though we do not currently expect a significant impact.

Risk Factors Relating to Our Indebtedness

Our indebtedness includes covenants and obligations with regard to our business activities that may restrict our ability to take certain actions which may negatively affect our financial condition.

At December 31, 2025, we had no outstanding indebtedness under our five-year $120.0 million senior secured credit facility (the “UMB Credit Agreement”), dated December 23, 2025. We must comply with customary affirmative and negative covenants contained in the UMB Credit Agreement, some of which may restrict the way in which we conduct our business. Among other things, these requirements could potentially limit our ability to:

● incur additional indebtedness or liens;

● sell assets;

● make loans or investments;

● make guarantees;

● enter into any hedging agreement for speculative purposes;

● acquire or be acquired by other companies; or

● amend some of our contracts.

The restrictions under our indebtedness may prevent us from engaging in certain transactions which might otherwise be considered beneficial to us, for example, they could:

We may incur additional indebtedness in the future by issuing debt instruments, under new credit agreements, under joint venture agreements, under capital leases or synthetic leases, on a project-finance or other basis or a combination of these. If we incur additional indebtedness in the future, it likely would be under arrangements that may have terms and conditions at least as restrictive as those contained in our UMB Credit Agreement. At December 31, 2025, available capacity to borrow on the revolving lines of credit was $60.0 million. Failure to comply with the terms and conditions of any existing or future indebtedness, including current or prospective covenants, would constitute an event of default. If an event of default occurs, the lenders will have the right to accelerate the maturity of such indebtedness and foreclose upon the collateral, if any, securing that indebtedness.

Our variable rate indebtedness subjects us to interest rate risk, which could cause our debt service obligations to increase significantly.

Borrowings under the UMB Credit Agreement allow for loans at variable rates of interest and expose us to interest rate risk. If interest rates increase, our debt service obligations on the variable rate indebtedness will increase even though the

Table of Contents

amount borrowed will remain the same, and our net income and operating cash flows, including cash available for servicing our indebtedness, will correspondingly decrease. Additionally, rising interest rates may increase our cost of capital and, therefore, reduce the amount of capital available to fund our operations.

In the future, we may enter into interest rate swaps and other derivative instruments that involve the exchange of floating for fixed rate interest payments in order to reduce interest rate volatility. However, we may not maintain those instruments with respect to all of our variable rate indebtedness, and any instruments we enter into may not fully mitigate our interest rate risk and subject us to counter-party credit risk.

Our bonding requirements may limit our ability to incur indebtedness.

We generally are required to provide various types of surety bonds that provide an additional measure of security for our performance under certain government and private sector contracts. Our ability to obtain surety bonds depends upon various factors including our capitalization, working capital and amount of our indebtedness. In order to help ensure that we can obtain required bonds, we may be limited in our ability to incur additional indebtedness that may be needed for potential acquisitions and operations. Our inability to incur additional indebtedness could have a material adverse effect on our business, operating results and financial condition.

Item 1B. UNRESOLVED STAFF COMMENTS

None.

Item 1C. CYBERSECURITY

Risk Management and Strategy

We have implemented and maintain a robust cybersecurity program to safeguard our information systems and protect the confidentiality, integrity and availability of our data.

Managing material risks & integrated overall risk management

We have strategically integrated cybersecurity risk management into our broader enterprise risk management framework to promote a company-wide culture of cybersecurity risk management. This integration ensures that cybersecurity considerations are an integral part of our decision-making processes at every level. Our information technology (“IT”) department continuously evaluates and addresses cybersecurity risks in alignment with our business objectives and operational needs.

Cybersecurity insurance coverage

Our internal cybersecurity risk management processes are supported by cybersecurity insurance that we have secured through industry leading underwriters. We believe that our cybersecurity insurance provides sufficient coverage to protect our assets, operations, and our employees from the financial impact of any cyber-attacks.

Engage third parties on risk management

Recognizing the complexity and evolving nature of cybersecurity threats, we engage with a range of external experts, including cybersecurity insurers, assessors, consultants and auditors in evaluating and assessing our risk management systems. These partnerships enable us to leverage specialized knowledge and insights, ensuring our cybersecurity strategies and processes remain at the forefront of industry best practices. Our collaboration with these third parties includes regular audits, threat assessments and consultation on security enhancements.

Table of Contents

Material cybersecurity incidents

We are not aware of any cybersecurity incidents that have materially affected or are reasonably likely to materially affect our results of operations, financial condition or financial reporting responsibilities, business strategy or performance historically.

Governance

The Board’s role in overseeing cybersecurity risk

The Board of Directors (the “Board”) is acutely aware of the critical nature of managing cybersecurity risks. Given the potential significance of cybersecurity threats to our operational integrity and stakeholder confidence, the Board has established robust oversight mechanisms to ensure effective governance in managing our cybersecurity risks. The Board is comprised of directors with varying backgrounds and expertise, including risk management, technology and finance, equipping them to oversee cybersecurity risks effectively.

In addition to our scheduled Board meetings, the Board, Chief Executive Officer (“CEO”), Chief Financial Officer (“CFO”), and Vice-President of Information Technology (“VPIT”) maintain an ongoing dialogue regarding emerging or potential cybersecurity risks, ensuring the Board’s oversight is proactive and responsive. The Board actively participates in strategic decisions related to cybersecurity, offering guidance and approval for major initiatives. This involvement ensures that cybersecurity considerations are integrated into our broader strategic objectives. The Board conducts an annual review of our cybersecurity program and the effectiveness of our applicable risk management strategies. This review helps in identifying areas for improvement and ensuring the alignment of our cybersecurity efforts with our overall risk management framework.

Management’s role in managing cybersecurity risk

Our CEO, CFO, and VPIT play a pivotal role in informing the Board regarding cybersecurity risks. They provide an annual comprehensive briefing to the Board, as well as interim updates throughout the year, as needed. The VPIT holds a master’s degree in business and has approximately 18 years of experience spanning enterprise IT, technology operations, and risk management, with responsibility for the Company’s cybersecurity program. The VPIT is supported by a team that includes individuals with long-standing information security experience. Our executive leadership team (composed of our CEO, CFO, and other senior officers representing functional and business areas) has ultimate management responsibility for our cybersecurity program, although primary responsibility rests with the VPIT, as described below. The executive leadership team meets regularly to discuss our strategy, opportunities and risks, including our risk management measures used to identify and mitigate cybersecurity threats.

Risk management personnel

Primary responsibility for assessing, monitoring and managing our cybersecurity risks rests with the VPIT. Our VPIT oversees our governance programs, tests our compliance with standards, remediates known risks and leads our employee training program. Reporting to our VPIT are a number of experienced information security officers responsible for various parts of our business, each of whom is supported by a team of trained cybersecurity professionals.

Monitoring cybersecurity incidents

The VPIT stays informed about the latest developments in cybersecurity, including potential threats and innovative risk management techniques. This ongoing knowledge acquisition is crucial for the effective prevention, detection, mitigation and remediation of cybersecurity incidents. The VPIT implements and oversees processes for the regular monitoring of our information systems. This includes the deployment of advanced security measures and regular system audits to identify potential vulnerabilities. In the event of a cybersecurity incident, the VPIT is equipped with a well-defined, robust incident response plan. This plan includes immediate actions to mitigate the impact, report the incident, if required, and develop and implement long-term strategies for the remediation and prevention of future incidents.

Table of Contents

Internal communication of cybersecurity matters

The VPIT regularly informs the executive leadership team of cybersecurity risks and incidents. This ensures that the highest levels of management are kept abreast of the cybersecurity posture and potential risks we face. Furthermore, significant cybersecurity matters, and strategic risk management decisions are escalated to the Board on a timely basis, ensuring that the Board has comprehensive oversight and can provide guidance on critical cybersecurity issues.

External reporting of cybersecurity matters

We have adopted protocols by which certain cybersecurity incidents that meet established reporting thresholds are escalated and, where appropriate, reported promptly to the public. We have empowered a cross-functional team of management to determine whether established reporting thresholds have been met and whether public disclosure is necessary or required.

Item 2. PROPERTIES

Our corporate headquarters is located at 2940 Riverby Road, Suite 400, Houston, Texas 77020. The lease for the corporate headquarters and operations offices includes approximately 63,500 square feet of office space with a term expiring in 2036, subject to two five-year extensions at our option.

We lease office space in Alaska, Arizona, Hawaii, Louisiana, Florida, Texas and Washington for our operations, including office and yard space. We may lease smaller project-related offices throughout our operating areas when the need arises.

We believe that our existing facilities are adequate for our operations. We do not believe that any single facility is material to our operations and, if necessary, we could readily obtain a replacement facility. Some of our real estate assets are pledged to secure the UMB Credit Agreement.

Item 3. LEGAL PROCEEDINGS

Please refer to Note 16 of the Notes to the Consolidated Financial Statements for a discussion of legal proceedings.

Item 4. MINE SAFETY DISCLOSURES

Not applicable.

PART II

Item 5. MARKET FOR REGISTRANT’S COMMON EQUITY, RELATED STOCKHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES

Market information

Our common stock is listed on the New York Stock Exchange and NYSE Texas and trades under the symbol “ORN.”

Holders

As of February 20, 2026, we had approximately 13,079 stockholders of record including beneficial holders.

Unregistered sales of equity securities and use of proceeds

There were no unregistered sales or issuer purchases of equity securities during the quarter ended December 31, 2025.

Issuer repurchase of equity securities

None.

Table of Contents

Performance graph*

The following graph shows the changes in the value of $100 invested in (1) the common stock of Orion Group Holdings, Inc., (2) the Standard & Poor’s 500 Stock Index, (3) the Standard & Poor’s Composite 1500 Construction Index and (4) the Dow Jones Heavy Construction Group Index. The values of each investment are based on share price appreciation, with reinvestment of all dividends, assuming any were paid. For each graph, the investments are assumed to have occurred at the beginning of each period.

Beginning with this Annual Report, the Company added the S&P 1500 Construction Index as an additional industry comparison, which is expected to be used in the Company’s compensation programs during the year ending December 31, 2026. The Company currently expects to discontinue the Dow Jones U.S. Heavy Civil Construction Index comparison beginning with next year’s performance graph. The Dow Jones index is included in this year’s graph to provide comparability to the index used in the immediately preceding fiscal year.

* This table and the information therein are being furnished but not filed. Such information will not be deemed to be soliciting material or incorporated by reference into any filing under the Securities Act of 1933, as amended, or the Securities Exchange Act of 1934, as amended, except to the extent that it is specifically incorporated by reference.

Securities authorized for issuance under equity compensation plans

The information required by Item 201(d) of Regulation S-K is hereby incorporated by reference from our definitive proxy statement to be filed with the SEC pursuant to Regulation 14A no later than April 30, 2026.

Table of Contents

Item 6. RESERVED

Item 7. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS

OF OPERATIONS

The following discussion and analysis of our financial condition and results of operations is based on and should be read in conjunction with our consolidated financial statements and the accompanying notes beginning on page F-1 of this Annual Report on Form 10-K. Certain statements made in our discussion may be forward-looking. Forward-looking statements involve risks and uncertainties and a number of other factors that could cause actual results or outcomes to differ materially from our expectations. See “Forward-Looking Statements” at the beginning of this Annual Report on Form 10-K for additional discussion of some of these risks and uncertainties. Unless the context requires otherwise, when we refer to the “Company,” “we,” “us” and “our,” we are describing Orion Group Holdings, Inc. and its consolidated subsidiaries and affiliates.

Overview

We are a leading specialty construction company serving the infrastructure, industrial, and building sectors, providing services both on and off the water in the continental United States, Alaska, Hawaii, Canada and the Caribbean Basin through our marine segment and our concrete segment.

Our marine segment provides construction and dredging services, including marine transportation facility construction, marine pipeline construction, construction of marine environmental structures, dredging of waterways, channels, and ports, environmental dredging, engineering and design, and specialty services related to marine construction, fabrication, and dredging.

Our concrete segment provides turnkey concrete construction services, including concrete placement and finishing, site preparation, layout, forming, and rebar placement for large commercial, structural, and other concrete projects.

Our contracts are obtained primarily through competitive bidding in response to “requests for proposals” by federal, state and local agencies and through negotiation and competitive bidding with private parties and general contractors. Our bidding activity and strategies are affected by factors such as our backlog, current utilization of equipment and other resources, job location, our ability to obtain necessary surety bonds and competitive considerations. The timing and location of awarded contracts may result in unpredictable fluctuations in the results of our operations.

Most of our revenue is derived from fixed-price contracts. We record revenue on construction contracts over time, measured by the percentage of actual contract costs incurred to date to total estimated costs for each contract. There are a number of factors that can create variability in contract performance and therefore impact the results of our operations.

The most significant of these include the following:

● completeness and accuracy of the original bid;

● increases in commodity prices such as concrete, steel and fuel;

● subcontractor performance;

● unforeseen site conditions;

● availability and skill level of workers; and

● a change in availability and proximity of equipment and materials.

All of these factors can have a negative impact on our contract performance, which can adversely affect the timing of revenue recognition and ultimate contract profitability. We plan our operations and bidding activity with these factors in mind and they generally have not had a material adverse impact on the results of our operations in the past.

Table of Contents

Recent Developments

JEM Acquisition

On February 3, 2026, we entered into a Securities Purchase Agreement (the “JEM Purchase Agreement”) and completed an acquisition (the “JEM Acquisition”) of all of the capital stock of J.E. McAmis, Inc., a California corporation, and all of the membership interests in JEM Marine Leasing, LLC, a Washington limited liability company (collectively, “JEM”).

The purchase price consisted of: (a) $50.0 million in cash, subject to adjustments pursuant to the purchase agreement; a $12.0 million unsecured subordinated promissory note issued to the sellers; and 182,392 shares of Orion’s common stock, and (b) contingent post-closing cash payments dependent upon project profit realized from contracts of JEM under backlog identified in the JEM Purchase Agreement. The cash consideration and related expenses was funded with cash on hand and borrowings of approximately $46.9 million under the UMB Credit Agreement (as defined below).

JEM is engaged in the business of providing dredging, jetty and breakwater construction, environmental restoration and rehabilitation, and dam and spillway construction.

UMB Credit Agreement

On December 23, 2025, we entered into a five-year $120.0 million Credit Agreement (the “UMB Credit Agreement”) with certain financial institutions from time-to-time party thereto, as lenders, and UMB Bank, N.A., as administrative agent and issuing bank. The UMB Credit Agreement consists of a $60.0 million revolving loan, a $20.0 million equipment term loan, and a $40.0 million acquisition term loan.

2025 Recap and 2026 Outlook

In 2025, we recorded revenues of $852 million, an increase of 7% as compared with 2024. $545 million of total revenue was attributable to our marine segment and the remaining $307 million to our concrete segment. Our net income was $2.5 million, as compared with net loss of $1.6 million in the prior year. In addition, we ended 2025 with a consolidated backlog of $640 million.

Looking to 2026, we will continue to execute our strategic plan focused on developing opportunities across the infrastructure, industrial, and building sectors.

Marine segment

Demand for our marine construction services remains strong, supported by our differentiated capabilities, specialized equipment fleet, and diversified service offerings within the marine construction industry. We continue to pursue opportunities that support the maintenance, repair, and expansion of infrastructure that facilitates the movement of goods and people across waterways. Long-term demand is driven by the expansion of the Panama Canal, the continued increase in the size of global shipping fleets, and the resulting need for U.S. ports and private marine infrastructure owners to deepen channels, strengthen wharves, and modernize marine structures to accommodate larger vessels.

In addition to port and navigation-related work, demand for marine construction services continues to be supported by public-sector infrastructure investment, coastal restoration initiatives, and energy-related marine construction. We believe our current equipment fleet and operating capabilities position us well to compete for and execute projects across both public and private end markets.

Over the long term, we expect favorable demand trends for our marine segment, driven by:

● Continued investment in U.S. Navy and other federal marine infrastructure;

Table of Contents

Concrete segment

Demand for our concrete segment’s services remains steady, although the timing of certain project releases may be affected by inflationary pressures, interest rate uncertainty, labor availability, supply chain constraints, and broader macroeconomic conditions. We continue to see favorable long-term demand fundamentals for our concrete construction services, supported by population growth, business expansion, and infrastructure investment across our core and expanding markets.

In Texas, major metropolitan areas and surrounding suburban corridors continue to experience strong population and commercial growth, supporting demand for warehouse and distribution facilities, education and institutional projects, office and retail development, grocery stores, multi-family housing, and structural concrete work for business, residential, and mixed-use developments. Texas also continues to see growth in data center construction, supported by the availability of developable land and access to power and fiber infrastructure. In addition, we are seeing increasing opportunities in other high-growth markets, including Florida, which supports our strategy to selectively expand our geographic footprint and diversify our revenue base.

Over the long term, we expect favorable demand trends for our concrete segment, driven by:

Beginning in the first quarter of fiscal 2026,we will update our reportable segments to better align with how management evaluates performance and allocates resources. Specifically, we will no longer allocate our corporate expenses to our operating segments. Rather, corporate expenses will be reported as a separate non-operating segment.

Consolidated results of operations

Backlog information

Our contract backlog represents our estimate of the revenues we expect to realize under the portion of contracts remaining to be performed. Given the typical duration of our contracts, which is generally less than a year, our backlog at any point in time usually represents only a portion of the revenue that we expect to realize during a twelve-month period. We have

Table of Contents

not been adversely affected by contract cancellations or modifications in the past; however, we may be in the future, especially in periods of economic uncertainty.

Backlog as of the periods ended below are as follows (in millions):

Backlog is not necessarily indicative of future results. In addition to our backlog under contract, we also have a substantial number of projects in negotiation or pending award at any given time.

Income statement comparisons

Year Ended December 31,

Amount Amount Amount

(dollar amounts in thousands)

Amortization of intangible assets — — 427

Gain on disposal of assets, net (2,468) (2,898) (8,455)

Intangible asset impairment loss — — 6,890

Other (expense) income:

Loss on extinguishment of debt (3,777)

Year ended December 31, 2025 compared with year ended December 31, 2024

Contract revenues. Contract revenues for the year ended December 31, 2025 of $852.3 million increased $55.9 million or 7% as compared to $796.4 million in the prior year period. The increase was primarily due to new awards and higher volume across the business.

Gross profit. Gross profit was $105.6 million for the year ended December 31, 2025 compared to $91.2 million in the prior year period, an increase of $14.4 million or 16%. Gross profit in the year ended December 31, 2025 was 12% of total contract revenues as compared to 11% in the prior year period. The increase was primarily driven by strong project execution and increased utilization.

Selling, general and administrative expense.Selling, General and Administrative (“SG&A”) expenses were $93.5 million for the year ended December 31, 2025 compared to $82.5 million in the prior year period, an increase of $11.0 million or 13%. As a percentage of total contract revenues, SG&A expenses increased from 10% to 11%. The increase in SG&A expense was primarily driven by spending to support business growth.

Table of Contents

Gain on disposal of assets, net. During the year ended December 31, 2025 and 2024 we realized $2.5 million and $2.9 million, respectively, of net gains on disposal of assets.

Other income, net of expense. Other expense primarily reflects interest on our borrowings and expenses related to the extinguishment of debt, partially offset by interest income and non-operating gains or losses.

Income tax expense. We recorded tax expense of $0.4 and $0.3 million in the years ending December 31, 2025 and 2024, respectively.

Year ended December 31, 2024 compared with year ended December 31, 2023

Contract revenues. Contract revenues for the year ended December 31, 2024 of $796.4 million increased $84.6 million or 11.9% as compared to $711.8 million in the prior year period. The increase was primarily due to an increase in marine segment revenue related to the Pearl Harbor drydock project, partially offset by lower concrete segment revenue due to disciplined bidding standards to win quality work at attractive margins.

Gross profit. Gross profit was $91.2 million for the year ended December 31, 2024 compared to $61.7 million in the prior year period, an increase of $29.5 million or 47.8%. Gross profit in the year ended December 31, 2024 was 11.4% of total contract revenues as compared to 8.7% in the prior year period. The increase in gross profit dollars and margin was primarily driven by improved pricing of projects in both segments stemming from higher quality projects and improved execution.

Selling, general and administrative expense.SG&A expenses were $82.5 million for the year ended December 31, 2024 compared to $69.4 million in the prior year period, an increase of $13.1 million or 18.9%. As a percentage of total contract revenues, SG&A expenses increased from 9.8% to 10.4%. The increase in SG&A dollars and percentage reflect an increase in IT, compensation, business development spending, and higher legal costs related to pursuing project-related claims.

Gain on disposal of assets, net. During the year ended December 31, 2024 and 2023 we realized $2.9 million and $8.5 million, respectively, of net gains on disposal of assets. The year ended December 31, 2023 included a gain of $5.2 million related to the sale-leaseback of our Port Lavaca South Yard property in Texas.

Other expense, net. Other expense primarily reflects interest on our borrowings of $13.4 million and $11.7 million in the years ended December 31, 2024 and 2023, respectively, partially offset by interest income and non-operating gains or losses.

Income tax expense. We recorded tax expense of $0.3 million in both the year ended December 31, 2024 and in the prior year period. Our effective tax rate for the year ended December 31, 2024 was (26.9)%, which differs from the federal statutory rate of 21% primarily due to the tax impact from the valuation allowance for current year activity, the statue expiration of an uncertain tax position, state income taxes and the non-deductibility of other permanent items.

Table of Contents

Segment results

The following table sets forth, for the periods indicated, statements of operations data by segment, segment revenues as a percentage of consolidated revenues and segment operating income (loss) as a percentage of segment revenues.

Year ended December 31,

Amount Amount Amount

(dollar amounts in thousands)

Contract revenues

Marine segment

Concrete segment

Operating income (loss)

Year ended December 31, 2025 compared with year ended December 31, 2024

Marine Segment

Revenues for our marine segment for the year ended December 31, 2025 were $544.8 million compared to $521.3 million for the year ended December 31, 2024, an increase of $23.5 million, or 5%. The increase was primarily due to new awards and higher volume on our marine construction contracts.

Operating income for our marine segment for the year ended December 31, 2025 was $29.9 million, compared to $2.3 million for the year ended December 31, 2024, an increase in operating income of $27.6 million. This increase in operating income was primarily driven by increased revenue, strong project execution, and favorable utilization.

Concrete Segment

Revenues for our concrete segment for the year ended December 31, 2025 were $307.4 million compared to $275.1 million for the year ended December 31, 2024, an increase of $32.3 million, or 12%. The increase was primarily due to new awards and higher volume on our concrete contracts.

Operating loss for our concrete segment for the year ended December 31, 2025 was $15.3 million, compared to an operating income of $9.2 million for the year ended December 31, 2024, a decrease of $24.5 million. The decrease was primarily driven by seasonal weather delays and favorable concrete project close-outs in 2024 that did not reoccur in 2025.

Year ended December 31, 2024 compared with year ended December 31, 2023

Marine Segment

Revenues for our marine segment for the year ended December 31, 2024 were $521.3 million compared to $395.9 million for the year ended December 31, 2023, an increase of $125.4 million, or 31.7%. The increase was primarily related to the Pearl Harbor Project.

Table of Contents

Operating income for our marine segment for the year ended December 31, 2024 was $2.3 million, compared to $3.7 million for the year ended December 31, 2023, a decrease in operating income of $1.4 million. Excluding the gain on the Port Lavaca South Yard property sale-leaseback in Texas that occurred during the year ended December 31, 2023, operating loss for the year ended December 31, 2023 was $1.5 million. This $3.8 million increase in operating income was primarily due to margin improvements stemming from higher quality projects and improved execution.

Concrete Segment

Revenues for our concrete segment for the year ended December 31, 2024 were $275.1 million compared to $315.9 million for the year ended December 31, 2023, a decrease of $40.8 million, or 12.9%. This decrease was primarily due to disciplined bidding standards to win quality work at attractive margins.

Operating income for our concrete segment for the year ended December 31, 2024 was $9.2 million, compared to an operating loss of $10.3 million for the year ended December 31, 2023, an increase of $19.5 million. This increase was primarily due to winning higher margin jobs due to disciplined bidding standards and improved execution.

Liquidity and capital resources

Changes in working capital are normal within our business given the varying mix in size, scope, seasonality and timing of delivery of our projects. At December 31, 2025, our working capital was $74.3 million, as compared to $78.2 million at December 31, 2024. As of December 31, 2025, we had unrestricted cash on hand of $1.6 million. Our borrowing availability under our revolving portion of our UMB Credit Agreement at December 31, 2025 was approximately $60.0 million.

Our primary liquidity needs are to finance our working capital and fund capital expenditures. Historically, our sources of liquidity have been cash provided by our operating activities, sale of underutilized assets, borrowings under our credit facilities, and equity issuances. The assessment of our liquidity requires us to make estimates of future activity and judgments about whether we are compliant with financial covenant calculations under our debt and other agreements and have adequate liquidity to operate. Significant assumptions used in our forecasted model of liquidity include forecasted sales, costs, and capital expenditures, as well as expected timing and proceeds of planned asset sale transactions. As of December 31, 2025, management believes the Company will have adequate liquidity for its operations for at least the next 12 months.

In connection with the JEM Acquisition, we borrowed $46.9 million under the UMB Credit Agreement and issued a $12.0 million promissory note to the sellers. The promissory note bears interest at an annual rate of 6.0%, with five equal payments of principal and interest on each anniversary of the closing of the Purchase Agreement.

The following table provides information regarding our cash flows and our capital expenditures for the years ending December 31, 2025, 2024 and 2023:

Year ended

December 31,

Cash flows provided by operating activities $ 28,066 $ 12,676 $ 17,178

Table of Contents

Operating activities.

During 2025, we generated approximately $28.1 million from cash in our operating activities. The net cash inflow is comprised of $43.9 million of cash inflows from net income, after adjusting for non-cash items, partially offset by $15.8 million of outflows related to changes in net working capital. The changes in net working capital, which are reflected as changes in operating assets and liabilities in our Consolidated Statements of Cash Flows, were primarily driven by a $67.1 million cash outflow related to a decrease in our net position of accounts receivable and accounts payable plus accrued liabilities during the period, a $7.3 million decrease in operating lease liabilities, and a $3.7 million cash outflow related to an increase in prepaid expenses, partially offset by $55.1 million of cash inflows pursuant to the relative timing and significance of project progression and billings during the period and a $6.5 million inflow from landlord lease incentives received, primarily related to our corporate office consolidation.

During 2024, we generated approximately $12.7 million from cash in our operating activities. The net cash inflow is comprised of $34.4 million of cash inflows from net income, after adjusting for non-cash items and $21.7 million of cash outflows related to changes in net working capital. The changes in net working capital, which are reflected as changes in operating assets and liabilities in our Consolidated Statements of Cash Flows, were primarily driven by $19.6 million of cash outflows pursuant to the relative timing and significance of project progression and billings during the period, a $8.7 million decrease in operating lease liabilities and $0.4 million of other outflows, partially offset by a $7.0 million cash inflow related to an increase in our net position of accounts receivable and accounts payable plus accrued liabilities during the period.

During 2023, we generated approximately $17.2 million in cash from our operating activities. The net cash inflow is comprised of $14.8 million of cash inflows from net income, after adjusting for non-cash items and $2.4 million of cash inflows related to changes in net working capital. The changes in net working capital, which are reflected as changes in operating assets and liabilities in our Consolidated Statements of Cash Flows, were primarily driven by a $21.4 million inflow related to an increase in our net position of accounts receivable and accounts payable plus accrued liabilities during the period, partially offset by a $11.3 million outflow pursuant to the relative timing and significance of project progression and billings during the period, a $6.8 million decrease in operating lease liabilities during the period, and $0.9 million of other cash outflows.

Investing activities.

During the year ended December 31, 2025, we used approximately $13.7 million of cash in our investing activities. Capital asset additions and betterments to our fleet were $38.9 million in 2025, as compared with $14.1 million and $8.9 million in 2024 and 2023, respectively. Proceeds from the sale of property and equipment were $25.2 million in 2025, as compared with $2.6 million and $11.1 million in 2024 and 2023, respectively.

Financing activities.

During the year ended December 31, 2025, we used approximately $39.4 million of cash in our financing activities. We had borrowings and repayments of $185.5 million on the White Oak revolving credit line, repayments of $23.0 million on the White Oak term loan, payments on finance lease liabilities of $10.4 million, payments made on deemed financing obligations of $8.2 million, a $1.1 million make-whole payment on debt extinguishment and $1.6 million outflow related to loan costs related to the new UMB Credit Agreement. These amounts were partially offset by an inflow of $4.5 million of proceeds from deemed financing obligation for build-to-suit equipment to be placed in service in 2026.

During the year ended December 31, 2024, we had proceeds from an offering of common stock of $26.4 million, borrowings and repayments of $72.6 million on the White Oak revolving credit line, repayments of $15.0 million on the White Oak term loan, payments on finance lease liabilities of $8.9 million, payments made on failed sale-leaseback arrangements of $5.8 million, $0.5 million of payments related to tax withholding for share-based compensation, repayments of $0.5 million on other debt, loan costs of $0.4 million and a cash inflow of $0.9 million for proceeds from the exercise of stock options.

During the year ended December 31, 2023, we had borrowings of $5.0 million from our prior credit agreement, $38.0 million from the term loan portion of our new Credit Agreement and borrowings of $64.0 million on the revolving credit line under our new Credit Agreement, repayments of $40.0 million on our prior credit agreement, repayments of $64.0

Table of Contents

million on the revolving credit line under our new Credit Agreement, proceeds from failed sales-leasebacks of $14.7 million, proceeds of $2.4 million related to the Port Lavaca land sale-leaseback financing, loan costs of $6.5 million, payments on finance lease liabilities of $4.8 million and a cash outflow of $0.5 million for payments related to tax withholdings for share-based compensation.

Sources of capital

On December 23, 2025, we entered into the five-year $120 million UMB Credit Agreement, which includes a $60.0 million asset based revolving credit line, a $20.0 million equipment term loan, and a $40 million acquisition term loan. The UMB Credit Agreement replaced our $103.0 million Credit Agreement with White Oak, which was a $65.0 million asset based revolving credit line and a $38.0 million fixed asset term loan.

Please see Note 9 of the Notes to the Consolidated Financial Statements for further discussion.

Effect of inflation

We are subject to the effects of inflation through increases in the cost of raw materials, and other items such as fuel, concrete and steel. Due to the relatively short-term duration of our projects, we are generally able to include anticipated cost increases in the pricing of our bids.

Off balance sheet arrangements

Currently our only off-balance sheet arrangements are related to providing surety bonds on certain government and private sector contracts and those which arise in the normal course of business. These arrangements are not reasonably likely to have an effect on our financial condition, revenues or expenses, results of operations, liquidity, capital expenditures, or capital resources that is material to investors.

Critical accounting estimates

The consolidated financial statements contained in this report were prepared in accordance with U.S. GAAP. The preparation of these financial statements in conformity with U.S. GAAP requires management to make estimates and assumptions that affect both the Company’s carrying values of its assets and liabilities, and the reported amounts of revenues and expenses during the reporting period. Actual results could differ from those estimates. Although our significant accounting policies are described in more detail in Note 2 of the Notes to Consolidated Financial Statements; we believe the following accounting policies to be critical to the judgments and estimates used in the preparation of our financial statements:

● Revenue Recognition from Construction Contracts;

● Long Lived Assets; and

● Income Taxes.

Revenue recognition

Our revenue is derived from contracts to provide marine construction, dredging, turnkey concrete services, and other specialty services. Our projects are typically short in duration and usually span a period of less than one year. We determine the appropriate accounting treatment for each contract before work begins and record revenue on contracts over time.

Performance obligations are promises in a contract to transfer distinct goods or services to the customer and are the unit of account under Topic 606. Our contracts and related change orders typically represent a single performance obligation because individual goods and services are not separately identifiable and we provide a significantly integrated service. Revenue is recognized over time because control is continuously transferred to the customer. For contracts with multiple performance obligations, we allocate the contract’s transaction price to each performance obligation using our best estimate of the stand-alone selling price of each distinct good or service. Progress is measured by the percentage of actual contract costs incurred to date to total estimated costs for each contract. This method is used because management considers contract costs incurred to be the best available measure of progress on these contracts. These estimates are subject to uncertainties and require judgment. Estimates of contract costs include all direct costs, such as material and

Table of Contents

labor, and those indirect costs incurred that are related to contract performance such as payroll taxes and insurance. General and administrative costs are charged to expense as incurred. Upfront costs, such as incurring costs to mobilize personnel and equipment prior to satisfying a performance obligation are capitalized and amortized over the contract performance period.

These estimates consider historical performance, the complexity of the work to be performed, the estimated time to complete the project, and other economic factors such as inflation and market rates. Changes in job performance, job conditions and estimated profitability, including those arising from final contract settlements, may result in revisions to costs and reported revenue and are recognized in the period in which the revisions are determined. The effect of changes in estimates of contract revenue or contract costs is recognized as an adjustment to recognized revenue on a cumulative catch-up basis. When losses on uncompleted contracts are anticipated, the entire loss is recognized in the period in which such losses are determined. Revenue is recorded net of any sales taxes collected and paid on behalf of the customer, if applicable.

Contract revenue is derived from the original contract price as modified by agreed-upon change orders and estimates of variable consideration related to incentive fees and change orders or claims for which price has not yet been agreed by the customer. We estimate variable consideration based on our assessment of the most likely amount to which we expect to be entitled. Variable consideration is included in the estimated recognition of revenue to the extent it is probable that a significant reversal of cumulative recognized revenue will not occur. A determination that the collection of a claim is probable is based upon our evaluation of its compliance with the terms of the contract and the extent to which we performed in accordance therewith but does not guarantee collection in full.

Long-lived assets

Our long-lived assets consist primarily of equipment used in our operations. Fixed assets are carried at cost and are depreciated over their estimated useful lives, ranging from one to 30 years, using the straight-line method for financial reporting purposes and accelerated methods for tax reporting purposes. The carrying value of our long-lived assets is evaluated periodically based on utilization of the asset and physical condition of the asset, as well as the useful life of the asset to determine if adjustment to the depreciation period or the carrying value is warranted. If events and circumstances such as poor utilization or deteriorated physical condition indicate that the asset(s) should be reviewed for possible impairment, we use projections to assess whether future cash flows, including disposition, on a non-discounted basis related to the tested assets are likely to exceed the recorded carrying amount of those assets to determine if an impairment exists. If we identify a potential impairment, we will estimate the fair value of the asset through known market transactions of similar equipment and other valuation techniques, which could include the use of similar projections on a discounted cash flow basis. We will report a loss to the extent that the carrying value of the impaired assets exceeds their fair values.

Income taxes

We determine our consolidated income tax provision using the asset and liability method prescribed by U.S. GAAP, which requires the recognition of income tax expense for the amount of taxes payable or refundable for the current period and for deferred tax liabilities and assets for the future tax consequences of events that have been recognized in an entity’s financial statements or tax returns. We must make significant assumptions, judgments and estimates to determine our current provision for income taxes, our deferred tax assets and liabilities, and any valuation allowance to be recorded against any deferred tax asset. The current provision for income tax is based upon the current tax laws and our interpretation of these laws, as well as the probable outcomes of any tax audits. The value of any net deferred tax asset depends upon estimates of the amount and category of future taxable income reduced by the amount of any tax benefits that we do not expect to realize. The factors used to assess the likelihood of realization include our forecast of future taxable income exclusive of reversing temporary differences and carryforwards, future reversals of existing taxable temporary differences and available tax planning strategies that could be implemented to realize the net deferred tax assets.

We consider both positive and negative evidence when evaluating the need for a valuation allowance on our deferred tax assets in accordance with Accounting Standards Codification (“ASC”) 740. Available evidence includes historical financial information supplemented by currently available information about future years. Generally, historical financial information is more objectively verifiable than projections of future income and is therefore given more weight in our assessment. We consider cumulative losses in the most recent twelve quarters to be significant negative evidence that is difficult to overcome in considering whether a valuation allowance is required. Conversely, we consider a cumulative

Table of Contents

income position over the most resent twelve quarters, to be significant positive evidence that a valuation allowance may not be required.

Actual operating results and the underlying amount and category of income in future years could render current assumptions, judgments and estimates of recoverable net deferred taxes inaccurate, thus impacting our financial position and results of operations. We compute deferred income taxes using the liability method. Under the liability method, deferred tax assets and liabilities are recognized for the future tax consequences attributable to differences between the financial statement carrying amounts of existing assets and liabilities and their respective tax bases. Deferred tax assets and liabilities are measured using enacted tax rates expected to apply to taxable income in the years in which those temporary differences are expected to be recovered or settled. Under the liability method, the effect on deferred tax assets and liabilities of a change in tax rates is recognized in income in the period that includes the enactment date.

We account for uncertain tax positions in accordance with the provisions of the Financial Accounting Standards Board’s ASC 740-10, which prescribes a recognition threshold and measurement attribute for financial statement disclosure of tax positions taken, or expected to be taken, on our consolidated tax return. We evaluate and record any uncertain tax positions based on the amount that management deems is more likely than not to be sustained upon ultimate settlement with the tax authorities in the tax jurisdictions in which we operate.

Item 7A. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

In the normal course of business, our results of operations are subject to risks related to fluctuations in commodity prices and fluctuations in interest rates. Historically, our exposure to foreign currency fluctuations has not been material and has been limited to temporary field accounts located in foreign countries where we perform work. Foreign currency fluctuations were immaterial in this reporting period.

Commodity price risk

We are subject to fluctuations in commodity prices for concrete, steel products and fuel. Although we routinely attempt to secure firm quotes from our suppliers, we generally do not hedge against increases in prices for commodity products. Commodity price risks may have an impact on our results of operations due to the fixed-price nature of many of our contracts, although the short-term duration of our projects may allow us to include cost increases to the pricing of our bids.

Interest rate risk

At December 31, 2025, we had no outstanding borrowings under our Credit Agreement.

Item 8. FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA

The information required by this Item 8 is submitted as a separate section beginning on page F-1 of this Annual Report on Form 10-K and is incorporated herein by reference.

Item 9. CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURE

None.

Item 9A. CONTROLS AND PROCEDURES

Evaluation of disclosure controls and procedures

Disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934, as amended (the “Exchange Act”)) are designed to provide reasonable assurance that information required to be disclosed by us in reports that we file or submit under the Exchange Act is recorded, processed, summarized, and reported within the time periods specified in SEC rules and forms, and is accumulated and communicated to management, including our principal executive officer and principal financial officer, as appropriate, to allow timely decisions regarding required disclosure.

Table of Contents

Based on management’s evaluation with the participation of our principal executive officer and principal financial officer, as of the end of the period covered by this Annual Report on Form 10-K, our principal executive officer and principal financial officer have concluded that our disclosure controls and procedures were effective as of December 31, 2025.

Changes in internal control over financial reporting

During the year ended December 31, 2025, we implemented new reporting systems and made changes to related internal controls. There have been no other changes to our internal control over financial reporting (as defined in Rules 13a-15(f) and 15d-15(f) under the Exchange Act) that occurred during the year ended December 31, 2025 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

Management’s report on internal control over financial reporting

Management is responsible for establishing and maintaining adequate internal control over financial reporting (as defined in Rule 13a-15(f) of the Exchange Act). Our internal control over financial reporting is designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles in the United States. Our system of internal control over financial reporting includes policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of our assets; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with U.S. generally accepted accounting principles and that receipts and expenditures are being made only in accordance with authorizations of our management; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use or disposition of our assets that could have a material effect on our consolidated financial statements.

Management, under the oversight of our principal executive officer and principal financial officer, and Audit Committee, assessed the effectiveness of our internal control over financial reporting as of December 31, 2025 using the criteria set forth by the Committee of Sponsoring Organizations of the Treadway Commission in Internal control - An Integrated Framework (“2013 Framework”). Based on its assessment, management has concluded that our internal control over financial reporting was effective as of December 31, 2025 at the reasonable assurances level.

Our independent registered public accounting firm, KPMG LLP, who audited the consolidated financial statements included in this annual report, has audited the effectiveness of our internal control over financial reporting as of December 31, 2025. KPMG LLP’s report appears on page F-4 of this Annual Report on Form 10-K.

Item 9B. OTHER INFORMATION

Director and Officer Trading Arrangements.

During the quarter ended December 31, 2025, no director or officer of Orion adopted or terminated any “Rule 10b5-1 trading arrangement” or “non-Rule 10b5-1 trading arrangement,” as such terms are defined in Item 408(a) of Regulation S-K.

Item 9C. DISCLOSURE CONCERNING CERTAIN FOREIGN JURISDICTIONS THAT PREVENT

INSPECTIONS

Not applicable.

PART III

Item 10. DIRECTORS, EXECUTIVE OFFICERS AND CORPORATE GOVERNANCE

Directors, Executive Officers, Promoters and Control Persons

The information under the heading “Information about our executive officers” in this Annual Report on Form 10-K is incorporated by reference into this section. The information required by Paragraphs (c) through (g) of Item 401 of

Table of Contents

Regulation S-K and Item 405 of Regulation S-K is hereby incorporated by reference from our definitive proxy statement to be filed with the SEC pursuant to Regulation 14A no later than April 30, 2026 (the “Proxy Statement”).

Code of Ethics

We have adopted a code of ethics for our chief executive, chief financial and principal accounting officers; a code of business conduct and ethics for members of our Board of Directors; and corporate governance guidelines. The full texts of the codes of ethics and corporate governance guidelines are available at our website www.oriongroupholdingsinc.com. Although we have never done so, in the event we make any amendment to, or grant any waiver from, a provision of the code of ethics that applies to the principal executive officer, principal financial officer or principal accounting officer that requires disclosure under applicable SEC rules, we will disclose such amendment or waiver and the reasons therefore on our website. We will provide any person without charge a copy of any of the aforementioned codes of ethics upon receipt of a written request. Requests should be addressed to: Orion Group Holdings, Inc. 2940 Riverby Road, Suite 400, Houston, Texas 77020, Attention: Corporate Secretary.

Corporate governance

The information required by Items 407(c)(3), (d)(4) and (d)(5) and 408(b) of Regulation S-K is hereby incorporated by reference from our Proxy Statement.

Item 11. EXECUTIVE COMPENSATION

The information required by Items 402, 407(e)(4) and 407(e)(5) of Regulation S-K is hereby incorporated by reference from our Proxy Statement.

Item 12. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED STOCKHOLDER MATTERS

The information required by Items 201(d) and 403 of Regulation S-K is hereby incorporated by reference from our Proxy Statement.

Item 13. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS, AND DIRECTOR INDEPENDENCE

The information required by Items 404 and 407(a) of Regulation S-K is hereby incorporated by reference from our Proxy Statement.

Item 14. PRINCIPAL ACCOUNTANT FEES AND SERVICES

The information required by Item 9(e) of Schedule 14A is hereby incorporated by reference from our Proxy Statement.

PART IV

Item 15. EXHIBITS AND FINANCIAL STATEMENT SCHEDULES

The following documents are filed as part of this Report:

1.Financial Statements

The Company’s Consolidated Financial Statements at December 31, 2025 and 2024 and for each of the three years in the period ended December 31, 2025 and the notes thereto, together with the Report of the Independent Registered Public Accounting Firm on those Consolidated Financial Statements are hereby filed as part of this Report, beginning on page F-1.

2.Financial Statement Schedule

The following financial statement schedule of the Company for each of the three years in the period ended December 31, 2025 is filed as part of this Report and should be read in conjunction with the Consolidated Financial Statements of the Company.

Table of Contents

Schedule II – Schedule of Valuation and Qualifying Accounts

3. Exhibits

ExhibitNumber Description

Table of Contents

ExhibitNumber Description

Table of Contents

ExhibitNumber Description

* 21 .1 List of Subsidiaries.

* 23 .1 Consent of Independent Registered Public Accounting Firm -KPMG, LLP.

* 31 .1 Certification of CEO pursuant to Section 302.

* 31 .2 Certification of CFO pursuant to Section 302.

* 32 .1 Certification of CEO and CFO pursuant to Section 906.

*101.INS XBRL Instance Document.

*101.SCH XBRL Taxonomy Extension Schema Document.

*101.CAL XBRL Extension Calculation Linkbase Document.

*101.DEF XBRL Taxonomy Extension Definition Linkbase Document.

*101.LAB XBRL Taxonomy Extension Label Linkbase Document.

*101.PRE XBRL Taxonomy Extension Presentation Linkbase Document.

Table of Contents

ExhibitNumber Description

* Filed herewith

† Management contract or compensatory plan or arrangement

Item 16. FORM 10-K SUMMARY

None.

Table of Contents

SIGNATURES

Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the Registrant has duly caused this Report to be signed on its behalf by the undersigned, thereunto duly authorized.

ORION GROUP HOLDINGS, INC.

ORN US Equity

ORN · 10-K · period ended 2025-12-31

Item 1A. RISK FACTORS

Item 1B. UNRESOLVED STAFF COMMENTS

Item 1C. CYBERSECURITY

Item 2. PROPERTIES

Item 3. LEGAL PROCEEDINGS

Item 4. MINE SAFETY DISCLOSURES

Item 5. MARKET FOR REGISTRANT’S COMMON EQUITY, RELATED STOCKHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES

Item 6. RESERVED

Item 7. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS

Item 7A. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

Item 8. FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA

Item 9. CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURE

Item 9A. CONTROLS AND PROCEDURES

Item 9B. OTHER INFORMATION

Item 9C. DISCLOSURE CONCERNING CERTAIN FOREIGN JURISDICTIONS THAT PREVENT

Item 10. DIRECTORS, EXECUTIVE OFFICERS AND CORPORATE GOVERNANCE

Item 11. EXECUTIVE COMPENSATION

Item 12. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED STOCKHOLDER MATTERS

Item 13. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS, AND DIRECTOR INDEPENDENCE

Item 14. PRINCIPAL ACCOUNTANT FEES AND SERVICES

Item 15. EXHIBITS AND FINANCIAL STATEMENT SCHEDULES

Item 16. FORM 10-K SUMMARY

ORN US Equity☆

ORN · 10-K · period ended 2025-12-31

Item 1A. RISK FACTORS

Item 1B. UNRESOLVED STAFF COMMENTS

Item 1C. CYBERSECURITY

Item 2. PROPERTIES

Item 3. LEGAL PROCEEDINGS

Item 4. MINE SAFETY DISCLOSURES

Item 5. MARKET FOR REGISTRANT’S COMMON EQUITY, RELATED STOCKHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES

Item 6. RESERVED

Item 7. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS

Item 7A. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

Item 8. FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA

Item 9. CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURE

Item 9A. CONTROLS AND PROCEDURES

Item 9B. OTHER INFORMATION

Item 9C. DISCLOSURE CONCERNING CERTAIN FOREIGN JURISDICTIONS THAT PREVENT

Item 10. DIRECTORS, EXECUTIVE OFFICERS AND CORPORATE GOVERNANCE

Item 11. EXECUTIVE COMPENSATION

Item 12. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED STOCKHOLDER MATTERS

Item 13. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS, AND DIRECTOR INDEPENDENCE

Item 14. PRINCIPAL ACCOUNTANT FEES AND SERVICES

Item 15. EXHIBITS AND FINANCIAL STATEMENT SCHEDULES

Item 16. FORM 10-K SUMMARY

ORN US Equity