ESOA · Read the filing

Table of Contents

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

FORM 10-K

☒ ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the Fiscal Year ended September 30, 2021

☐ TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the transition period from ____________________ to ____________________

Commission File Number: 001-32998

Energy Services of America Corporation

(Exact Name of Registrant as Specified in its Charter)

75 West 3rd Ave., Huntington, West Virginia 25701

(Address of Principal Executive Office) (Zip Code)

(304) 522-3868

(Registrant’s Telephone Number including area code)

Securities Registered Pursuant to Section 12(b) of the Act:

Title of Each Class Trading Symbol Name of Each ExchangeOn Which Registered

None None None

Securities Registered Pursuant to Section 12(g) of the Act:

Common Stock, par value $0.0001 per share

(Title of Class)

Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. YES ☐NO☒

Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act. YES ☐NO☒

Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports) and (2) has been subject to such filing requirements for the past 90 days. YES☒ NO ☐

Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T (§ 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit such files). YES⌧ NO ◻

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definition of “large accelerated filer,” “accelerated filer”, “smaller reporting company”, and an “emerging growth company” in Rule 12b-2 of the Exchange Act.

Large accelerated filer ☐ Accelerated filer ☐

Non-accelerated filer ☒ Smaller reporting company ☒

Emerging growth company ☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

Indicate by check mark whether the registrant has filed a report on and attestation to its management's assessment of the effectiveness of its internal control over financial reporting under Section 404(b) of the Sarbanes-Oxley Act (15 U.S.C. 7262(b)) by the registered public accounting firm that prepared or issued its audit report. ◻

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). YES ☐ NO ☒

The aggregate market value of the voting and non-voting common equity held by non-affiliates of the Registrant, computed by reference to the closing price on March 31, 2021, was $ 13,654,316.

As of December 28, 2021, there were issued and outstanding 17,466,328 and 16,247,898, respectively, shares of the Registrant’s Common Stock.

DOCUMENTS INCORPORATED BY REFERENCE

None

Table of Contents

Energy Services of America Corporation

Annual Report on Form 10-K

For the Fiscal Year Ended

September 30, 2021

Table of Contents

ITEM 1. Business 3

ITEM 1A. Risk Factors 10

ITEM 1B. Unresolved Staff Comments 14

ITEM 2. Properties 14

ITEM 3. Legal Proceedings 14

ITEM 4. Mine Safety Disclosures 14

ITEM 6. Reserved 15

ITEM 7A. Quantitative and Qualitative Disclosures about Market Risk 29

ITEM 8. Financial Statements and Supplementary Data 29

ITEM 9A. Controls and Procedures 29

ITEM 9B. Other Information 30

ITEM 10. Directors, Executive Officers and Corporate Governance 31

ITEM 11. Executive Compensation 35

ITEM 14. Principal Accountant Fees and Services 40

ITEM 15. Exhibits and Financial Statement Schedules 42

ITEM 16. Form 10-K Summary 43

Signatures. 44

Table of Contents

Forward Looking Statements

Within Energy Services’ (as defined below) consolidated financial statements and this Annual Report on Form 10-K, there are included statements reflecting assumptions, expectations, projections, intentions or beliefs about future events that are intended as “forward-looking statements” under the Private Securities Litigation Reform Act of 1995. You can identify these statements by the fact that they do not relate strictly to historical or current facts. They use words such as “anticipate,” “estimate,” “project,” “forecast,” “may,” “will,” “should,” “could,” “expect,” “believe,” “intend” and other words of similar meaning.

These forward-looking statements are not guaranteeing future performance and involve or rely on risks, uncertainties, and assumptions that are difficult to predict or beyond Energy Services’ control. Energy Services has based its forward-looking statements on management’s beliefs and assumptions based on information available to management at the time the statements are made. Actual outcomes and results may differ materially from what is expressed, implied and forecasted by forward-looking statements and any or all of Energy Services’ forward-looking statements may turn out to be wrong. The accuracy of such statements can be affected by inaccurate assumptions and by known or unknown risks and uncertainties.

All the forward-looking statements, whether written or oral, are expressly qualified by these cautionary statements and any other cautionary statements that may accompany such forward-looking statements or that are otherwise included in this report. In addition, Energy Services does not undertake and expressly disclaims any obligation to update or revise any forward-looking statements to reflect events or circumstances after the date of this report or otherwise.

PART I

ITEM 1.Business

Overview

Energy Services of America Corporation (“Energy Services” or the “Company”), formed in 2006, is a contractor and service company that operates primarily in the mid-Atlantic region of the United States and provides services to customers in the natural gas, petroleum, water distribution, automotive, chemical, and power industries. C.J. Hughes Construction Company, Inc. (“C.J. Hughes”), a wholly owned subsidiary of the Company, is a general contractor primarily engaged in pipeline construction for utility companies. Contractors Rental Corporation (“Contractors Rental”), a wholly owned subsidiary of C.J. Hughes, provides union building trade employees for projects managed by C.J. Hughes. Nitro Construction Services, Inc. (“Nitro”), a wholly owned subsidiary of C.J. Hughes, provides electrical, mechanical, HVAC/R, solar installation, and fire protection services to customers primarily in the automotive, chemical, and power industries. Pinnacle Technical Solutions, Inc. (“Pinnacle”), a wholly owned subsidiary of Nitro, operates as a data storage facility within Nitro’s office building. Pinnacle is supported by Nitro and has no employees of its own. All C.J. Hughes, Nitro, and Contractors Rental construction personnel are union members of various related construction trade unions and are subject to collective bargaining agreements that expire at varying time intervals.

On December 31, 2020, Energy Services completed an asset purchase of West Virginia Pipeline, Inc. (“West Virginia Pipeline”), a West Virginia corporation located in Princeton, West Virginia. West Virginia Pipeline, a wholly owned subsidiary of Energy Services, operates as a gas and water distribution contractor primarily in southern West Virginia. West Virginia Pipeline’s employees are non-union, and the company is managed independently from C.J. Hughes and Nitro.

On March 22, 2021, the Company established a new wholly owned subsidiary, SQP Construction Group, Inc. (“SQP”), that operates as a general contractor primarily in West Virginia. SQP engages in the construction and renovation of buildings and other civil construction projects for state and local government agencies and commercial customers. As a general contractor, SQP manages the overall construction project and subcontracts most of the work.

On April 30, 2021, the Company’s Nitro subsidiary completed an asset purchase of Revolt Energy, Inc. (“Revolt Energy”), a West Virginia corporation located in Nitro, WV. Revolt Energy previously operated primarily as a residential solar installation company in southern West Virginia. As a division of Nitro, Revolt Energy continues to perform residential solar installations and has expanded its solar installation services to include commercial and industrial customers. Revolt Energy’s construction employees are members of the International Brotherhood of Electrical Workers.

Table of Contents

On June 30, 2021, the Company provided notice to all holders of the Company’s 6.0% Convertible Cumulative Perpetual Preferred Stock, Series A (“Series A Preferred Stock”) that, subject to applicable law and in accordance with the Company’s certificate of incorporation, the Company intended to redeem all 206 shares of the Series A Preferred Stock, at a price equal to $25,000 per preferred share plus all accrued and unpaid dividends whether or not declared up to and excluding the Redemption Date of September 1, 2021 (the “Redemption Price”).

A portion of the 206 outstanding shares of Series A Preferred Stock were converted into common stock of the Company (“Common Stock”) at the election of each shareholder. The conversion formula for each share of the Series A Preferred Stock was $25,000 plus all accrued but unpaid dividends up to, but excluding, September 1, 2021 divided by the Conversion Price of $1.50. Cash was issued in lieu of fractional shares at a rate of $1.50 multiplied by the fractional share rounded to the nearest cent.

On October 6, 2021, the Company’s transfer agent completed the redemption, which resulted in the issuance of 2,626,492 new shares of the Company’s common stock, the issuance of 317,500 common shares that were included in Series A Preferred Stock units, and cash redemption payments of $1.3 million. The Company’s total outstanding common shares after redemption was 16,247,898 as of October 6, 2021.

The Company’s stock is quoted under the symbol “ESOA” on the OTCQB marketplace operated by the OTC Markets Group.

Energy Services provides contracting services for utilities and energy related companies including gas, petroleum power, chemical, water & sewer and automotive industries. For the gas industry, the Company is primarily engaged in the construction, replacement and repair of natural gas pipelines and storage facilities for utility companies and private natural gas companies. Energy Services is involved in the construction of both interstate and intrastate pipelines, with an emphasis on the latter. For the oil industry, the Company provides a variety of services relating to pipeline, storage facilities and plant work. For the power, chemical, and automotive industries, the Company provides a full range of electrical and mechanical installations and repairs including substation and switchyard services, site preparation, equipment setting, pipe fabrication and installation, packaged buildings, transformers and other ancillary work with regards thereto. Energy Services’ other services include liquid pipeline construction, pump station construction, production facility construction, water and sewer pipeline installations, various maintenance and repair services and other services related to pipeline construction. The Company has also added the ability to install residential, commercial, and industrial solar systems and perform civil and general contracting services.

The Company had consolidated operating revenues of $122.5 million for the fiscal year ended September 30, 2021, of which 48.9% was attributable to electrical, mechanical, and general contract services, 33.0% to gas & water distributions services, and 18.1% to gas and petroleum transmission projects. The Company had consolidated operating revenues of $119.2 million for the fiscal year ended September 30, 2020, of which 43.4% was attributable to electrical, mechanical, and general contract services, 36.1% to gas and petroleum transmission projects, and 20.5% to gas & water distributions services.

Energy Services’ customers include many of the leading companies in the industries it serves, including:

TransCanada Corporation

Columbia Gas Distribution

Marathon Petroleum

Mountaineer Gas

American Electric Power

Toyota Motor Manufacturing

Bayer Chemical

Dow Chemical

Kentucky American Water

WV American Water

Various state, county and municipal public service districts.

The majority of the Company’s customers are located in West Virginia, Virginia, Ohio, Pennsylvania, and Kentucky. However, the Company also performs work in other states including Alabama, Michigan, Illinois, Tennessee, and Indiana.

Energy Services’ sales force consists of industry professionals with significant relevant sales experience, who utilize industry contacts and available public data to determine how to most appropriately market the Company’s line of products. The Company relies

Table of Contents

on direct contact between its sales force and customers’ engineering and contracting departments in order to obtain new business. The Company’s website address is www.energyservicesofamerica.com.

COVID-19 Response

In March 2020, the World Health Organization recognized the novel strain of coronavirus, COVID-19, as a pandemic. This coronavirus and related variants have significantly impacted both the world and U.S. economies. In response the governments of many cities, counties, states, and other geographic regions have taken preventative or protective actions. In the geographic regions in which the Company operates, state ordered business closures and masking policies have been lifted during 2021; however, some businesses may implement their own policies related to masks and vaccination. While a federal vaccine mandate enforceable by OSHA has been suspended pending developments in litigation, certain customers, or potential customers, may require all construction employees working on a project to be vaccinated.

Some of the procedures that the Company has implemented to help protect employees from COVID-19 and variant exposure are guidelines for social distancing, office sanitation, hand washing, mask wearing, limited office admittance, and immediate symptom reporting. The Company has provided personal protective equipment and hand-sanitizers to employees, made arrangements for administrative personnel to work from home, and provided access to vaccines to employees. The Company works closely with our customers to limit exposure risk and cooperate with symptom reporting and contact tracing. Construction employees are required to meet all procedures established by our customers in addition to the Company’s own procedures. The Company also followed the paid sick and expanded family and medical leave guidelines set forth in the Families First Coronavirus Response Act, which expired on December 31, 2020.

As of September 30, 2021, the Company has not had significant issues with COVID-19 exposure among its employees and most of the Company’s existing customers had resumed projects that were affected by the March 2020 shutdowns. As a result, the Company has increased its employment level of construction personnel as compared to March 31, 2020. Given the uncertainty regarding the spread of this coronavirus and variants, the related financial impact on the Company’s results of operations, financial position, and liquidity or capital resources cannot be reasonably estimated at this time.

Seasonality: Fluctuation of Results

Our revenues and results of operations can and usually are subject to seasonal variations. These variations are the result of weather, customer spending patterns, bidding seasons and holidays. The first quarter of the calendar year is typically the slowest in terms of revenues because inclement weather conditions causes delays in production and customers usually do not plan large projects during that time. While usually better than the first quarter, the second calendar year quarter often has some inclement weather which can cause delays in production, reducing the revenues the Company receives and/or increasing the production costs. The third and fourth calendar year quarters usually are less impacted by weather and usually have the largest number of projects underway. Many projects are completed in the fourth calendar year quarter and revenues are often impacted by customers seeking to either spend their capital budget for the year or scale back projects due to capital budget overruns.

In addition to the fluctuations discussed above, the pipeline industry can be highly cyclical, reflecting variances in capital expenditures in proportion to energy price fluctuations. As a result, our volume of business may be adversely affected by where our customers are in the cycle and thereby their financial condition as to their capital needs and access to capital to finance those needs.

Accordingly, our operating results in any quarter or year may not be indicative of the results that can be expected for any other quarter or any other year. You should read “Management’s Discussion and Analysis of Financial Condition and Results of Operations-Understanding Gross Margins” below for discussions of trends and challenges that may affect our financial condition and results of operations.

Financing Arrangements

On December 16, 2014, the Company’s Nitro subsidiary entered into a 20-year $1.2 million loan agreement with First Bank of Charleston, Inc. (West Virginia) to purchase the office building and property it had previously been leasing for $6,300 monthly. The interest rate on this loan agreement is 4.82% with monthly payments of $7,800. The interest rate on this note is subject to change from time to time based on changes in The U.S. Treasury yield, adjusted to a constant maturity of three years as published by the Federal

Table of Contents

Reserve weekly. As of September 30, 2021, the Company had made principal payments of $281,000. The loan is collateralized by the building purchased under this agreement.

On September 16, 2015, the Company entered into a $2.5 million Non-Revolving Note agreement with United Bank, Inc. This six-year agreement gave the Company access to a $2.5 million line of credit (“Equipment Line of Credit”), specifically for the purchase of equipment, for the period of one year with an interest rate of 5.0%. After the first year, all borrowings against the Equipment Line of Credit were converted to a five-year term note agreement with an interest rate of 5.0%. As of September 30, 2021, the Company had borrowed $2.46 million against this note and had paid off the loan, which was collateralized by the equipment purchased under this agreement.

On November 13, 2015, the Company entered into a 10-year $1.1 million loan agreement with United Bank, Inc. to purchase the fabrication shop and property Nitro had previously been leasing for $12,900 each month. The interest rate on the new loan agreement is 4.25% with monthly payments of $11,602. As of September 30, 2021, the Company had made principal payments of $569,000. The loan is collateralized by the building and property purchased under this agreement.

On June 28, 2017, the Company entered into a $5.0 million Non-Revolving Note agreement with United Bank, Inc. This five-year agreement gave the Company access to a $5.0 million line of credit (“Equipment Line of Credit 2017”), specifically for the purchase of equipment, for a period of three months with an interest rate of 4.99%. After three months, all borrowings against the Equipment Line of Credit 2017 were converted to a five-year term note agreement with an interest rate of 4.99%. As of September 30, 2021, the Company had borrowed $5.0 million against this note and made principal payments of $4.2 million. The loan is collateralized by the equipment purchased under this agreement.

On December 31, 2020, West Virginia Pipeline Acquisition Company, later renamed West Virginia Pipeline, Inc., entered into a $3.0 million sellers’ note agreement with David and Daniel Bolton for the remaining purchase price of West Virginia Pipeline, Inc. For the purchase price allocation, the $3.0 million note had a fair value of $2.85 million. As part of the $6.35 million fair acquisition, the acquirer paid $3.5 million in cash in addition to the note. The unsecured five-year term note requires equal annual payments with a fixed interest rate of 3.25% on the $3.0 million sellers’ note, which equates to 5.35% on the carrying value of the note. As of September 30, 2021, the Company has made interest payments of $73,000 and expensed $22,500 in accreted interest. The Company made the first installment payment in December 2021.

On January 4, 2021, the Company entered into a $3.0 million Non-Revolving Note agreement with United Bank, Inc. This five-year agreement gave the Company access to a $3.0 million line of credit (“Equipment Line of Credit 2021”), specifically for the purchase of equipment, for a period of twelve months with a variable interest rate initially established at 4.25% as based on the Prime Rate as published by The Wall Street Journal. After twelve months, all borrowings against the Equipment Line of Credit 2021 will be converted to a four-year term note agreement with a variable interest rate initially established at 4.25%. The loan is collateralized by the equipment purchased under this agreement. As of September 30, 2021, the Company borrowed $3.0 million against this line of credit with payments set to begin in February 2022. The Company has made interest payments of $34,000 on this note as of September 30, 2021.

On April 2, 2021, the Company entered into a $3.5 million Non-Revolving Note agreement with United Bank, Inc. This five-year agreement repaid the outstanding $3.5 million line of credit that was used for the down payment on the West Virginia Pipeline acquisition. This loan has a variable interest rate initially established at 4.25% as based on the Prime Rate as published by The Wall Street Journal. The loan is collateralized by the Company’s equipment and receivables. As of September 30, 2021, the Company had made principal payments of $316,000.

On August 3, 2021, the Company received a one-year extension on its line of credit (“Operating Line of credit (2020)”) effective June 28, 2021. The $15.0 million revolving line of credit has a $12.5 million component and a $2.5 million component, each with separate borrowing requirements. The interest rate on the line of credit is the “Wall Street Journal” Prime Rate (the index) with a floor of 4.99%. Based on the borrowing base calculation, the Company was able to borrow up to $12.2 million as of September 30, 2021. The Company had $4.5 million in borrowings on the line of credit, leaving $7.7 million available on the line of credit as of September 30, 2021. The interest rate at September 30, 2021, was 4.99%. Based on the borrowing base calculation, the Company was able to borrow up to $11.1 million as of September 30, 2020. The Company had no borrowings on the line of credit, leaving $11.1 million available on the line of credit as of September 30, 2020. The interest rate at September 30, 2020, was 4.99%.

Table of Contents

Paycheck Protection Program Loans

Due to the economic uncertainties created by COVID-19 and limited operating funds available, the Company applied for loans under the Paycheck Protection Program (“PPP”). On April 15, 2020, Energy Services of America Corporation and subsidiaries C.J. Hughes Construction Company, Contractors Rental Corporation and Nitro Construction Services, Inc. entered into separate PPP notes effective April 7, 2020, with United Bank, Inc. as the lender (“Lender”) in an aggregate principal amount of $13,139,100 pursuant to the PPP (collectively, the “PPP Loan”). In a special meeting held on April 27, 2020, the Board of Directors of the Company unanimously voted to return $3.3 million of the PPP Loan funds after discussing the financing needs of the Company and subsidiaries. That left the Company and subsidiaries with $9.8 million in PPP Loans to fund operations.

The Small Business Administration (“SBA”) has announced, in consultation with the Department of the Treasury, that it will review all loans in excess of $2 million, following the lender’s submission of the borrower’s loan forgiveness application. The SBA will be reviewing a borrower’s required certification that current economic uncertainty at the time of the loan made the PPP loan request necessary to support the ongoing operations of the applicant. Borrowers must make this certification in good faith, taking into account their current business activity and their ability to access other sources of liquidity sufficient to support their ongoing operations in a manner that is not significantly detrimental to the business. The SBA has noted it is unlikely that a public company with substantial market value and access to capital markets will be able to make the required certification in good faith, and such a company should be prepared to demonstrate to the SBA, upon request, the basis for its certification.

During fiscal year 2021, the Company received notice that the SBA had granted forgiveness of the $9.8 million of PPP borrowings and the SBA repaid the lending institution in full. The forgiveness was recorded as “other non-operating income” for the fiscal year ended September 30, 2021.

Borrowers must retain PPP documentation for at least 6 years after the date the loan is forgiven or paid in full, and the SBA and SBA Inspector General must be granted these files upon request. The SBA could still revisit its forgiveness decision and determine that the Company does not qualify in whole or in part for loan forgiveness and demand repayment of the loans. In addition, it is unknown what type of penalties could be assessed against the Company if the SBA disagrees with the Company’s certification. Any penalties in addition to the potential repayment of the PPP Loan could negatively impact the Company’s business, financial condition and results of operations and prospects.

Backlog/New Business

The Company’s backlog represents contracts for services that have been entered into, but which have not yet been completed. At September 30, 2021, Energy Services had a backlog of $72.2 million of work to be completed on existing contracts. At September 30, 2020, the Company had a backlog of $63.8 million. Due to the timing of Energy Services’ construction contracts and the long-term nature of some of our projects, portions of our backlog work may not be completed in the current fiscal year. Most of the Company’s projects can be completed in a short period of time, typically two to five months. Larger projects usually take seven to eighteen months to be completed. As a rule, work starts shortly after the signing of the contract.

Types of Contracts

Energy Services’ contracts are usually awarded on a competitive and negotiated basis. Whilesome contracts may be lump sum or time and material projects, most of the work is bid based upon unit prices for various portions of the work with a total agreed-upon price based on estimated units. The actual revenues produced from the project will be dependent upon how accurate the customer estimates are as to the units of the various items.

Raw Materials and Suppliers

The principal raw materials that the Company and its subsidiaries use are metal plate, structural steel, pipe, wire, fittings, and selected engineering equipment such as pumps, valves and compressors. For the most part, the largest portion of these materials are supplied by the customer. Purchases made by the Company are predominately those of a consumable nature, such as small tools, welding rod and environmental supplies. The COVID-19 pandemic has not had a significant impact on the Company’s ability to obtain materials and consumables for projects awarded. We anticipate being able to obtain materials for current work, as well as any raw materials not supplied by our customers, for the foreseeable future. However, the inability of our customers to obtain raw materials may delay projects

Table of Contents

from being bid, awarded, started, or completed. Although not a significant impact, the Company has experienced minor delays resulting from the availability of construction equipment and vehicles.

Industry Factors

Energy Services’ revenues, cash flows and earnings are substantially dependent upon, and affected by, the level of natural gas exploration development activity and the levels of work on existing pipelines as well as the level of demand for our electrical and mechanical services. Such activity and the resulting level of demand for pipeline construction and related services and electrical and mechanical services are directly influenced by many factors over which the Company has no control. Such factors include the market prices of natural gas and electricity, market expectations about future prices, the volatility of such prices, the cost of producing and delivering natural gas and electricity, government regulations and trade restrictions, local and international political and economic conditions, the development of alternate energy sources, changes in the tax code that affect the energy industry, and the long-term effects of worldwide energy conservation measures. Energy Services cannot predict the future level of demand for its construction services, future conditions in the pipeline or electrical construction industry or future pipeline and electrical construction rates.

Competition

The pipeline, electrical, and mechanical construction industries are highly competitive and characterized by high capital and maintenance costs. Contracts are usually awarded through a competitive bid process. The Company believes that operators consider factors such as quality of service, type and location of equipment, or the ability to provide ancillary services. However, price and the ability to complete the project in a timely manner are the primary factors in determining which contractor is awarded a job. There are many regional and national competitors that offer services similar to Energy Services. Certain of the Company’s competitors have greater financial and human resources than Energy Services, which may enable them to compete more efficiently because of price and technology. The Company’s largest competitors are Otis Eastern, Miller Pipeline, Brown Electric, Summit Electric and Apex Pipeline.

Operating Hazards and Insurance

Energy Services’ operations are subject to many hazards inherent in the pipeline, electrical, and mechanical construction businesses, including, for example, operating equipment in mountainous terrain, people working in deep trenches, people working near large construction equipment, and people working near manufacturing equipment and power sources. These hazards could cause personal injury or death, serious damage to or destruction of property and equipment, and substantial damage to the environment, including damage to producing formations and surrounding areas. Energy Services seeks protection against certain of these risks through insurance, including property casualty insurance on its equipment, commercial general liability and commercial contract indemnity, commercial umbrella and workers’ compensation insurance.

The Company’s insurance coverage for property damage to its equipment is based on estimates of the cost of comparable used equipment to replace the insured property. There is a deductible per occurrence on equipment of $2,500 and $500 for damage to miscellaneous tools. The Company also maintains third party liability insurance, pollution and professional liability insurance, and a commercial umbrella policy. Energy Services believes that it is adequately insured for public liability and property damage to others with respect to its operations. However, such insurance may not be enough to protect Energy Services against liability for all consequences related to its operations.

Government Regulation and Environmental Matters

General. Energy Services’ operations are affected from time to time in varying degrees by political developments and federal, state and local laws and regulations. In particular, natural gas production, operations and the profitability of the gas industry are or have been affected by price controls, taxes and other laws relating to the natural gas industry, by changes in such laws and by changes in administrative regulations. Although significant capital expenditures may be required to comply with such laws and regulations, to date, such compliance costs have not had a material adverse effect on the earnings or competitive position of Energy Services. In addition, Energy Services’ operations are vulnerable to risks arising from the numerous laws and regulations governing the discharge of materials into the environment or otherwise relating to environmental protection. Energy Services may also be affected by regulations designed to provide benefits to companies engaged in the production of alternative sources of energy, such as solar, wind, and related industries.

Environmental Regulation. Energy Services’ activities are subject to existing federal, state and local laws and regulations governing environmental quality, pollution control and the preservation of natural resources. Such laws and regulations concern, among

Table of Contents

other things, the containment, disposal and recycling of waste materials, and reporting of the storage, use or release of certain chemicals or hazardous substances. Numerous federal and state environmental laws regulate drilling activities and impose liability for discharges of waste or spills, including those in coastal areas. The Company has conducted pipeline construction in or near ecologically sensitive areas, such as wetlands and coastal environments, which are subject to additional regulatory requirements. State and federal legislation also provide special protections to animal and marine life that could be affected by the Company’s activities. In general, under various applicable environmental programs, the Company may potentially be subject to regulatory enforcement action in the form of injunctions, cease and desist orders and administrative, civil and criminal penalties for violations of environmental laws. Energy Services may also be subject to liability for natural resource damages and other civil claims arising out of a pollution event. The Company would be responsible for any pollution event that was determined to be caused by its actions. It has insurance that it believes is adequate to cover any such occurrences.

Environmental regulations that affect Energy Services’ customers also have an indirect impact on Energy Services. Increasingly stringent environmental regulation of the natural gas industry has led to higher drilling costs and a more difficult and lengthier well permitting process.

The primary environmental statutory and regulatory programs that affect Energy Services’ operations include the following: Department of Transportation regulations, regulations set forth by agencies such as the Federal Energy Regulatory Commission and various environmental agencies including the Environmental Protection Agency, and state and local government agencies.

Health and Safety Matters. Energy Services’ facilities and operations are also governed by various other laws and regulations, including the federal Occupational Safety and Health Act, relating to worker health and workplace safety. The Occupational Safety and Health Administration has issued the Hazard Communication Standard. This standard applies to all private-sector employers, including the natural gas exploration and producing industry. The Hazard Communication Standard requires that employers assess their chemical hazards, obtain and maintain certain written descriptions of these hazards, develop a hazard communication program and train employees to work safely with the chemicals on site. Failure to comply with the requirements of the standard may result in administrative, civil and criminal penalties. Energy Services believes that appropriate precautions are taken to protect employees and others from harmful exposure to materials handled and managed at its facilities and that it operates in substantial compliance with all Occupational Safety and Health Act regulations. It is not anticipated that Energy Services will be required to make material expenditures by reason of such health and safety laws and regulations.

Please see “COVID-19 Response” above to see the steps the Company has taken to ensure the health and safety of its workforce as it relates to the COVID-19 pandemic.

Research and Development/Intellectual Property

Energy Services has not made any material expenditure for research and development. Energy Services does not own any patents, trademarks or licenses.

Employees and Human Capital Resources

Energy Services of America believes the Company’s greatest asset is its employees. The Company’s emphasis on the health and safety of its employees is an important factor in maintaining its experienced workforce and attracting new talent. As of September 30, 2021, the Company had 703 employees including 274 full-time non-union employees.

The Company’s non-union construction, management, and administrative employees are all eligible to participate in the Company paid health, vision, dental, life, prescription, and long-term disability insurance plans. The Company also provides employee paid supplemental life and accident insurance plans. To encourage employees to keep up with routine medical care and participate in its wellness program, the Company funds a Health Reimbursement Account for participating employees. To help employees cover medical expenses pre-tax, the Company offers employees a Flexible Spending Account. The Company also offers employees a 401(k)-retirement plan with a Company match.

The Company’s union construction workers are represented by various collective bargaining units that provide health and welfare and retirement plans to their members. The Company’s top priority is the safety of our construction employees. The Company’s experienced safety department ensures that employees have the Company and customer required safety training before starting a project.

Table of Contents

Daily and weekly safety meetings at project sites help employees remain aware of potential hazards. Periodic internal and third-party safety audits are performed to help ensure that the Company’s and customer’s safety procedures are followed.

Early in the COVID-19 pandemic, the Company had customers that delayed or cancelled projects due to the uncertainty in the economy and health concerns. During this time, the Company attempted to keep as many of its employees working as possible by moving crews to different projects or shifting work responsibilities. The Company also worked closely to accommodate employees’ request to use the Families First Coronavirus Relief Act and the Family Medical Leave Act.

ITEM 1A.Risk Factors

Our business is subject to a variety of risks and uncertainties, including, but not limited to, the risk and uncertainties described below. The risks and uncertainties described below are not the only ones we may face. Additional risks and uncertainties not known to us or not described below also may impair our business operations. If any of the following risks actually occur, our business financial condition and results of operations could be impacted, and we may not be able to achieve our expectations, projections, intentions or beliefs about future events that are intended as “forward-looking statements” under Private Securities Litigation Reform Act of 1995 and should be read in conjunction with the section entitled “Forward looking statements”.

Risk Related to our Operations

Our operating results may vary significantly from quarter to quarter.

We typically experience lower volumes and lower margins during the winter months due to lower demand for our pipeline services and more difficult operating conditions. Also, other items that can materially affect our quarterly results include:

● Adverse weather;

● Variations in the mix of our work in any quarter;

● Shortage of qualified labor;

● Unfavorable regional, national or global economic and market conditions;

● A reduction in the demand for our services;

● Changes in customer spending patterns and need for the services we provide;

● Unanticipated increases in construction and design costs;

● Timing and volume of work we perform;

● Termination of existing agreements;

● Losses experienced not covered by insurance;

● Payment risks associated with customer financial condition;

● Changes in bonding requirements of agreements;

● Interest rate variations; and

● Changes in accounting and financial reporting standards.

Risk Related to our Business

The type of contracts we obtain could adversely affect our profitability.

We enter into various types of contracts, including fixed price and variable pricing contracts. On fixed price contracts our profits could be curtailed or eliminated by unanticipated pricing increases associated with the contract.

A portion of our business depends on our ability to provide surety bonds. We may be unable to compete on certain projects if we are not able to obtain the necessary surety bonds.

Current or future market conditions, including losses in the construction industry or as a result of large corporate bankruptcies, as well as changes in our surety providers’ assessment of our operating and financial risk, could cause our surety providers to decline to issue or renew, or substantially reduce the amount of bonds for our work or could increase our bonding costs. These actions could be taken on short notice. Since a growing number of our customers require such bonding, should our surety providers limit or eliminate our access to bonding, our performance could be negatively impacted if we are unable to replace the bonded business with work that

Table of Contents

does not require bonding or if we are unable to provide other means of securing the jobs performance such as with letters of credit or cash.

Many of our contracts can be cancelled or delayed or may not be renewed upon completion.

If our customers should cancel or delay many projects, our revenues could be reduced if we are unable to replace these contracts with others. Also, we have contracts that expire and are renewed periodically. If we are unsuccessful in renewing those contracts, that could reduce our revenue as well.

Our business requires a skilled labor force and if we are unable to attract and retain qualified employees, our ability to maintain our productivity could be impaired.

Our productivity depends upon our ability to employ and maintain skilled personnel to meet our requirements. Should some of our key managers leave the Company, it could limit our productivity. Also, many of our labor personnel are trade union members. Should we encounter labor problems associated with our union employees or if we are unable to employ enough available operators, welders, or other skilled labor, our production could be significantly curtailed.

Our backlog may not be realized.

Our backlog could be reduced due to cancellation of projects by customers and/or reductions in scope of the projects. Should this occur, our anticipated revenues would be reduced unless we are able to replace those contracts.

We extend credit to customers for purchases of our services and therefore have risk that they may not be able to repay us.

While we have not had any significant problems with collections of accounts receivables historically, should there be an economic downturn our customers’ ability to repay us could be compromised, and this may curtail our operations and ability to operate profitably.

Our dependence on suppliers, subcontractors and equipment manufacturers could expose us to risk of loss in our operations.

On certain projects, we rely on suppliers to obtain the necessary materials and subcontractors to perform portions of our services. We also rely on equipment manufacturers to provide us with the equipment needed to conduct our operations. Any limitation on the availability of materials or equipment or failure to complete work on a timely basis by subcontractors in a quality fashion could lead to added costs and therefore lower profitability for the Company.

We face cybersecurity risk including the breach of confidential personal information, Company or customer intellectual properties, and delays related to data loss.

Information technology systems are critical to our business. We use various technology systems to manage our customer relationships, general ledger and other systems. Our computer systems, data management and internal processes, as well as those of third parties, are integral to our performance. Our operational risks include the risk of malfeasance by employees or persons outside our company, errors relating to transaction processing and technology, systems failures or interruptions, breaches of our internal control systems, and business continuation and disaster recovery. There have been increasing efforts by third parties to breach data security. Such attacks include computer viruses, malicious or destructive code, phishing attacks, denial of service or information or other security breaches that could result in the unauthorized release, gathering, monitoring, misuse, loss or destruction of confidential, proprietary and other information, damages to systems, or other material disruptions to network access or business operations. Although we take protective measures and believe that we have not experienced any of the data breaches described above, the security of our computer systems, software, and networks may be vulnerable to breaches, unauthorized access, misuse, computer viruses, or other malicious code and cyber-attacks that could have an impact on information security. Because the techniques used to cause security breaches change frequently, we may be unable to proactively address these techniques or to implement adequate preventative measures.

The Company uses industry-leading firewall hardware and runs anti-malware, antivirus, and anti-exploit solutions on all computers as a first line of defense to prevent security breaches. The Company’s email software utilizes spam blocking, phishing filtering, and external sender warnings. The Company uses compartmentalized network drive access to mitigate ransomware damage and performs daily encrypted backups to secure offsite locations including a disaster recovery site.

Table of Contents

Risk Related to the COVID-19 Pandemic

We have operations in multiple states and face risks related to the Coronavirus/COVID 19 global pandemic that could impact our results of operations.

Our business could be adversely affected by the effects of the widespread outbreak of Coronavirus and related variants (“COVID-19”). The outbreak of COVID-19 and other adverse public health developments may have a material and adverse effect on our business operations. These could include disruptions or restrictions on our ability to travel or to complete our projects, as well as temporary closures of our facilities or the facilities of our suppliers or customers. Any disruption of our suppliers or customers would likely impact our operating results. In addition, the continued outbreak of COVID-19 could continue to adversely affect the economies of the states that we operate in resulting in a long-term economic downturn that could impact our operating results.

The SBA may review the Company’s PPP Loan forgiveness application and if the SBA disagrees with the Company’s certification the Company could be subject to penalties and the repayment of the PPP Loans, which could negatively impact the Company’s business, financial condition and results of operations and prospects.

In fiscal year 2021, the Company received notification of forgiveness on the $9.8 million in PPP loans received in calendar year 2020. The Company must retain PPP loan documentation in its files for six years after the date of forgiveness. The Company believes it meets the SBA’s certification requirement based on its limited access to capital, weakened business operations during the pandemic and small market value. The Company’s shares of common stock do not trade on a national exchange. However, no assurance can be given as to the outcome if the SBA re-evaluates the Company’s loan certification. The SBA could determine that the Company does not qualify in whole or in part for loan forgiveness. In addition, it is unknown what type of penalties could be assessed against the Company if the SBA disagrees with the Company’s certification. The Company could be required to repay its PPP Loans. Any penalties in addition to the potential repayment of the PPP Loans could negatively impact the Company’s business, financial condition and results of operations and prospects.

Risk Related to our Industry

An economic downturn in the industries we serve could lead to less demand for our services.

In addition to the effects of an economic recession, there could be reductions in the industries that the Company serves. If the demand for natural gas should drop dramatically, or the demand for electrical and mechanical services drops dramatically, these would in turn result in less demand for the Company’s services.

Project delays or cancellations may result in additional costs to us, reductions in revenues or the payment of liquidated damages.

In certain circumstances, we guarantee project completion by a scheduled acceptance date or are paid only upon achievement of certain acceptance and performance testing levels. Failure to meet any of these requirements could result in additional costs or penalties which could exceed the expected project profits.

Our industry is highly competitive.

Our industry has been and remains competitive with competitors ranging from small owner operated companies to large public companies. Within that group there may be companies with lower overhead costs that may be able to price their services at lower levels than we can. Accordingly, if that occurs, our business opportunities could be severely limited. In addition, our industry competes for energy demand with suppliers of alternative energy sources such as solar and wind.

Table of Contents

We may be unsuccessful at generating internal growth.

Our ability to generate internal growth will be affected by our ability to:

● Attract new customers;

● Expand our relationships with existing customers;

● Hire and maintain qualified employees;

● Expand geographically; and

● Adjust quickly to changes in our industry.

Risk Related to Financing

Credit facilities to fund our operations and growth might not be available.

Our business relies heavily on having lines of credit in place to fund the various projects we are working on. Should funding not be available, or on favorable terms, it could severely curtail our operations and the ability to generate profits. Energy Services maintains a banking relationship with two regional banks and has lines of credit and borrowing facilities with these institutions. On August 3, 2021, the Company renewed its $15.0 million Operating Line of Credit (2020) with United Bank, WV. Based on the borrowing base calculation, the Company could borrow up to $12.2 million as of September 30, 2021. The Company had borrowed $4.5 million on the line of credit, leaving $7.7 million available on the line of credit. The Company believes this line of credit will provide enough operating capital for future projects, but the Company cannot guarantee it will always have access to this line of credit in the future depending on the Company’s financial performance.

Risk Related to our Financial Performance

Revenue and cost estimates on projects may differ from actual results.

The preparation of these consolidated financial statements requires us to make estimates and assumptions that affect the reported amounts of revenues and expenses during the reporting period. We evaluate our estimates on an ongoing basis, based on historical experience and on various other assumptions that are believed to be reasonable under the circumstances. While the Company believes estimates on project performance are materially correct at September 30, 2021, there can be no assurance that actual results will not differ from those estimates.

Risk Related to Law and Regulatory Compliance

During the ordinary course of business, we may become subject to lawsuits or indemnity claims, which could materially and adversely affect our business and results of operations.

From time to time, we may in the ordinary course of business be named as a defendant in lawsuits, claims and other legal proceedings. These actions may seek, among other things, compensation for alleged personal injury, worker’s compensation, employment discrimination, breach of contract, property damages, civil penalties and other losses of injunctive or declaratory relief. Also, we often indemnify our customers for claims related to the services we provide and actions we take under our contracts with them. Because our services in certain instances may be integral to the operation and performance of our customers’ infrastructure, we may become subject to lawsuits or claims for any failure of the systems we work on. While we carry insurance to protect the Company against such claims, the outcomes of any of the lawsuits, claims or legal proceedings could result in significant costs and diversion of management’s attention from the business. Payments of significant amounts, even if reserved, could adversely affect our reputation, liquidity and results of operations.

We may incur liabilities or suffer negative financial or reputational harm relating to occupational health and safety matters.

Our operations are subject to extensive laws and regulations relating to the maintenance of safe conditions in the workplace. While we are constantly monitoring our health and safety programs, our industry involves a high degree of operating risk and there can be no assurance given that we will avoid significant liability exposure and/or be precluded from working for various customers due to high incident rates.

Table of Contents

While the Company encourages employees to receive COVID-19 vaccinations, enforcement of OSHA’s COVID-19 Vaccination and Testing Emergency Temporary Standard could result in lost productivity and additional expense for the Company.

Changes by the government in laws regulating the industries we serve could reduce our sales volumes.

If the government enacts legislation that has a serious impact on the industries we serve, it could lead to the curtailment of capital projects in those industries and therefore lead to lower sales volumes for our Company.

Our failure to comply with environmental laws could result in significant liabilities.

Our operations are subject to various environmental laws and regulations, including those dealing with the handling and disposal of waste products, polychlorinated biphenyls (PCBs) and other hazardous materials, as well as fuel storage. We also work around and under bodies of water. We invest significantly in compliance with the appropriate laws and regulations. However, if we should inadvertently cause contamination of waters or soils, liabilities for our Company relating to cleanup and remediation could be substantial and could exceed any insurance coverage we might have and result in a negative impact to the Company’s ability to operate.

ITEM 1B.Unresolved Staff Comments

None.

ITEM 2.Properties

The Company and its subsidiaries own the property where its subsidiaries, C.J. Hughes, Nitro, West Virginia Pipeline, and the Company’s headquarters are located. We maintain our executive offices at 75 West 3rd Ave., Huntington, West Virginia 25701, which is also the offices of C.J. Hughes and Contractors Rental. Nitro’s office is located at 4300 1st Ave., Nitro, WV 25143. West Virginia Pipeline’s office is located at 300 Pipeline Road, Princeton, WV 24739. SQP rents its office space and is located at 281 Smiley Drive, St Albans, WV 25177. The Company’s management believes that its properties are adequate for the business it conducts. Please see “Liquidity and Capital Resources” on page 27 for a description of the mortgages on the Nitro properties.

ITEM 3.Legal Proceedings

In February 2018, the Company filed a lawsuit against a former customer (“Defendant”) in the United States District Court for the Western District of Pennsylvania. The lawsuit is related to a dispute over work performed on a pipeline construction project. On November 9, 2021, the Company was awarded $5.8 million, none of which has been recognized in the Company’s financial statements. The Defendant has filed motions to request a new trial or a renewed judgement as a matter of law, which has not been ruled upon. The Company anticipates that a final judgement order will be issued in the first calendar quarter of 2022. A party to a civil lawsuit usually has 30 days from the entry of judgment to file a notice of appeal.

Other than described above, at September 30, 2021, the Company was not involved in any legal proceedings other than in the ordinary course of business. The Company is a party from time to time to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, punitive damages, civil penalties or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims, and proceedings, we record reserves when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. At September 30, 2021, the Company does not believe that any of these proceedings, separately or in aggregate, would be expected to have a material adverse effect on our financial position, results of operations or cash flows.

ITEM 4.Mine Safety Disclosures

None.

Table of Contents

PART II

ITEM 5.Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities

The Company’s common stock is quoted under the symbol “ESOA” and transactions in the stock are reported on the OTCQB marketplace.

The following table sets forth the range of high and low sales prices for common stock during each of the last two fiscal years and is based on information provided by the OTCQB. The high and low “bid price”, as required to be disclosed by Regulation S-K, was not available for certain periods because either these were not two-sided quotes by market makers or there was only one market maker with a two-sided quote. Over the counter market quotations reflect inter-dealer prices, without retail mark-up, markdown or commission and may not necessarily represent actual transactions.

Common Stock

Fiscal 2020 High Low Dividends

Fiscal 2021 High Low Dividends

As of December 16, 2021, there were 39 holders of record of our common stock. Certain shares of the Company’s common stock are held in “nominee” or “street” name and accordingly the number of beneficial owners of common stock is not included in the number of record holders.

On December 11, 2019, the Company declared a $0.05 per share special dividend that was paid on December 31, 2019, to common stockholders of record as of December 23, 2019. The special dividend totaled $696,117. The payment of cash dividends in the future will be contingent upon our revenues and earnings, if any, capital requirements and general financial condition. The payment of any future dividends will be within the discretion of our board of directors.

On August 22, 2019, the Company announced that the Board of Directors authorized a stock repurchase program under which the Company would purchase up to 10%, or approximately 1,393,393 shares, of the Company’s issued and outstanding stock. The purchase program started on August 26, 2019, and expired on August 26, 2020. The Company suspended the stock repurchase program on April 27, 2020. Accordingly, there were no repurchases in the Company’s fourth fiscal quarter in 2020. The program resulted in the repurchase of 312,522 shares through September 30, 2020. The Company did not repurchase any stock during the three and twelve months ended September 30, 2021.

At the annual meeting of shareholders on August 11, 2010, the shareholders approved the Energy Services of America Corporation Long Term Incentive Plan, to provide employees and directors of the Company with additional incentives to promote the growth and performance of the Company. The ten-year plan expired as of August 2020 with no awards in the fiscal year ended September 30, 2020. All stock grants have vested or been forfeited as of September 30, 2021.

ITEM 6. Reserved

Table of Contents

ITEM 7.Management’s Discussion and Analysis of Financial Condition and Results of Operations

You should read the following discussion of the financial condition and results of operations of Energy Services in conjunction with the historical financial statements and related notes contained elsewhere herein. Among other things, those historical consolidated financial statements include more detailed information regarding the basis of presentation for the following information.

Understanding Gross Margins

Our gross margin is gross profit expressed as a percentage of revenues. Cost of revenues consists primarily of salaries, wages and some benefits to employees, depreciation, fuel and other equipment costs, equipment rentals, subcontracted services, portions of insurance, facilities expense, materials and parts and supplies. Factors affecting gross margin include:

Seasonal. As discussed above, seasonal patterns can have a significant impact on gross margins. Usually, business is slower in the winter months versus the warmer months.

Weather. Adverse or favorable weather conditions can impact gross margin in each period. Periods of wet weather, snow or rainfall, as well as severe temperature extremes can severely impact production and therefore negatively impact revenues and margins. Conversely, periods of dry weather with moderate temperatures can positively impact revenues and margins due to the opportunity for increased production and efficiencies.

Revenue Mix. The mix of revenues between customer types and types of work for various customers will impact gross margins. Some projects will have greater margins while others that are extremely competitive in bidding may have narrower margins.

Service and Maintenance versus Installation. In general, installation work has a higher gross margin than maintenance work. This is because installation work usually is of a fixed price nature and therefore has higher risks involved. Accordingly, a higher portion of the revenue mix from installation work typically will result in higher margins.

Subcontract Work. Work that is subcontracted to other service providers generally has lower gross margins. Increases in subcontract work as a percentage of total revenues in each period may contribute to a decrease in gross margin.

Materials versus Labor. Typically, materials supplied on projects have lower margins than labor. Accordingly, projects with a higher material cost in relation to the entire job will have a lower overall margin.

Depreciation. Depreciation is included in our cost of revenue. This is a common practice in our industry but can make comparability to other companies difficult.

Margin Risk. Failure to properly execute a job including failure to properly manage and supervise a job could decrease the profit margin.

Selling, General and Administrative Expenses

Selling, general and administrative expenses consist primarily of compensation and related benefits to management, administrative salaries and benefits, marketing, communications, office and utility costs, professional fees, bad debt expense, letter of credit fees, general liability insurance and miscellaneous other expenses.

Table of Contents

Results of Operations for the Year Ended September 30, 2021, Compared to the Year Ended September 30, 2020.

Revenue. A table comparing the components of the Company’s revenues for the fiscal years ended September 30, 2021, and 2020 is below:

Fiscal Year Ended

Revenue increased by $3.3 million or 2.7% to $122.5 million for the fiscal year ended September 30, 2021, from $119.2 million for the fiscal year ended September 30, 2020.

Gas & Water Distribution revenues totaled $40.4 million for fiscal year ended September 30, 2021, a $16.0 million increase from $24.5 million for fiscal year ended September 30, 2020. The revenue increase was primarily related to the Company’s overall commitment to growing this line of business through adding new distribution crews and the acquisition of West Virginia Pipeline. West Virginia Pipeline, acquired on December 31, 2020, contributed revenues of $5.7 million for the fiscal year ended September 30, 2021.

Gas & Petroleum Transmission revenues totaled $22.1 million for fiscal year ended September 30, 2021, a $20.9 million decrease from $43.0 million for fiscal year ended September 30, 2020. The revenue decrease was primarily related to fewer project bid opportunities combined with greater competition from non-union and larger union bidders during fiscal year ended September 30, 2021. The Company was awarded several transmission projects that were delayed by the customer until later in the Company’s fourth quarter of fiscal year 2021. Those projects are expected to be completed in the Company’s first quarter of fiscal year 2022.

Electrical, Mechanical, & General services and construction revenues totaled $59.9 million for fiscal year ended September 30, 2021, an $8.2 million increase from $51.7 million for fiscal year ended September 30, 2020. The revenue increase was primarily due to a large automotive project, which started in fiscal year 2020 and was completed in fiscal year 2021. In addition, the Company had a significant amount of outage work that started in the fourth quarter of fiscal year 2021. SQP, started in March 2021, accounted for $3.1 million in revenue for fiscal year 2021.

Please see page F-31 of the Notes to Consolidated Financial Statements for a quarterly summary of revenues earned.

Cost of Revenues. A table comparing the components of the Company’s costs of revenues for fiscal years ended September 30, 2021 and 2020, is below:

Fiscal Year Ended

September 30, 2021 % of total September 30, 2020 % of total Change % Change

Total cost of revenues increased by $3.8 million or 3.6% to $109.5 million for fiscal year ended September 30, 2021, from $105.7 million for the fiscal year ended September 30, 2020.

Gas & Water Distribution cost of revenues totaled $32.5 million for the fiscal year ended September 30, 2021, a $12.4 million increase from $20.1 million for fiscal year ended September 30, 2020. The cost of revenues increase was primarily related to the Company’s overall commitment to growing this line of business through adding new distribution crews and the acquisition of West Virginia Pipeline. West Virginia Pipeline, acquired on December 31, 2020, incurred cost of revenues of $3.4 million for fiscal year ended September 30, 2021.

Table of Contents

Gas & Petroleum Transmission cost of revenues totaled $17.2 million for fiscal year ended September 30, 2021, a $15.2 million decrease from $32.4 million for fiscal year ended September 30, 2020. The cost of revenues decrease was primarily related to fewer project bid opportunities combined with greater competition from non-union and larger union bidders during fiscal year ended September 30, 2021.

Electrical, Mechanical, & General services and construction cost of revenues totaled $55.6 million for fiscal year ended September 30, 2021, a $7.1 million increase from $48.5 million for fiscal year ended September 30, 2020. The cost of revenues increase was primarily due to a large automotive project, which started in fiscal year 2020 and was completed in fiscal year 2021. In addition, the Company had a significant amount of outage work that started in the fourth quarter of fiscal year 2021. SQP, started in March 2021, accounted for $2.7 million in cost of revenues for fiscal year 2021.

Unallocated shop expenses totaled $4.3 million for fiscal year ended September 30, 2021, a $487,000 decrease from $4.8 million for fiscal year ended September 30, 2020. The decrease in unallocated shop expenses was due to increased internal equipment charges to projects for fiscal year ended September 30, 2021, as compared to 2020.

Gross Profit. A table comparing the components of the Company’s gross profit for fiscal years ended September 30, 2021, and 2020, is below:

Fiscal Year Ended

Gross profit percentage 10.6 % 11.3 %

Total gross profit decreased by $580,000 or (4.3%) to $12.9 million for fiscal year ended September 30, 2021, from $13.5 million for fiscal year ended September 30, 2020.

Gas & Water Distribution gross profit totaled $8.0 million for fiscal year ended September 30, 2021, a $3.6 million increase from $4.4 million for fiscal year ended September 30, 2020. The gross profit increase was primarily related to the Company’s overall commitment to growing this line of business through adding new distribution crews and the acquisition of West Virginia Pipeline. West Virginia Pipeline, acquired on December 31, 2020, contributed gross profit of $2.4 million for fiscal year ended September 30, 2021.

Gas & Petroleum Transmission gross profit totaled $4.9 million for fiscal year ended September 30, 2021, a $5.8 million decrease from $10.7 million for fiscal year ended September 30, 2020. The gross profit decrease was primarily related to fewer project bid opportunities combined with greater competition from larger union and non-union bidders during fiscal year ended September 30, 2021.

Electrical, Mechanical, & General services and construction gross profit totaled $4.3 million for fiscal year ended September 30, 2021, a $1.1 million increase from $3.2 million for fiscal year ended September 30, 2020. An increase in volume combined with more efficient production accounted for the increased gross profit. SQP, started in March 2021, accounted for $388,000 in gross profit for fiscal year 2021.

Gross loss attributed to unallocated shop expenses totaled $4.3 million for fiscal year ended September 30, 2021, a $487,000 decrease from $4.8 million for fiscal year ended September 30, 2020. The gross loss decrease was primarily due to increased internal equipment charges to projects for fiscal year ended September 30, 2021, as compared to 2020.

Selling and administrative expenses. Total selling and administrative expenses increased by $4.0 million to $13.8 million for fiscal year ended September 30, 2021, from $9.8 million for fiscal year ended September 30, 2020. Approximately $1.2 million of the selling and administrative expense increase for fiscal year ended September 30, 2021, was from the operations of the new subsidiaries, West Virginia Pipeline and SQP. In addition, the Company incurred approximately $150,000 in acquisition costs during the fiscal year ended September 30, 2021.

Table of Contents

The Company incurred higher labor costs for fiscal year ended September 30, 2021, compared to fiscal year ended September 30, 2020, primarily due to the Company investing approximately $962,000 in personnel to enhance project management and estimating in the transmission division, develop a quality assurance/quality control program, expand its mechanical services, and improve production tracking. Additionally, incentive compensation increased by $481,000 for fiscal year ended September 30, 2021, as compared to fiscal year ended September 30, 2020. The overall increase in selling and administrative expense, including an increase in incentive compensation, related to an initiative launched by the Company to increase and incentivize operational talent within the Company in order to increase revenue and profit margins.

A one-time $651,000 Qualified Non-Elective Contribution (“QNEC”) adjustment to the Company’s 401(k) plan (“Plan”) attributable to the 2021 Plan year increased selling and administrative costs for fiscal year ended September 30, 2021, as compared to fiscal year ended September 30, 2020. The reason for the QNEC adjustment was to correct Plan participant’s balances due to a third-party administrator’s actions.

(Loss) income from operations. Loss from operations was ($893,000) for fiscal year ended September 30, 2021, a $4.6 million decrease from a $3.7 million income from operations for the fiscal year ended September 30, 2020.

Interest Expense. Interest expense increased by $71,000 or 14.6% to $557,000 for the fiscal year ended September 30, 2021, from $486,000 for the fiscal year ended September 30, 2020. This increase was primarily due to increased line of credit borrowings and financing the West Virginia Pipeline acquisition and equipment purchases.

Other income (expenses). Other income totaled $10.0 million for fiscal year ended September 30, 2021, as compared to other expenses of ($93,000) for fiscal year ended September 30, 2020. The increase in other income was primarily related to $9.8 million of PPP loan debt forgiveness recognized during the fiscal year ended September 30, 2021. Please see the “Paycheck Protection Program Loans” disclosure on page 9.

Net Income. Income before income taxes was $9.1 million for fiscal year ended September 30, 2021, compared to $3.6 million for fiscal year ended September 30, 2020. The increase in income before income taxes was primarily due to PPP loan debt forgiveness, which was a one-time event that will not be repeated.

Income tax benefit for fiscal year ended September 30, 2021, was ($29,000) compared to income tax expense of $1.1 million for fiscal year ended September 30, 2020.

The effective income tax rate for fiscal year ended September 30, 2021, was (0.32%), as compared to 32.0% for fiscal year ended September 30, 2020. Effective income tax rates are estimates and may vary from period to period due to changes in the amount of taxable income and non-deductible expenses.

According to the Coronavirus Aid, Relief, and Economic Security Act (“CARES Act”) passed by Congress in March 2020, PPP loan forgiveness is not taxable. In accordance with the Consolidated Appropriations Act, 2021, the Company’s PPP related expenditures in fiscal year 2020 were considered deductible expenses for federal income tax purposes. The PPP forgiveness had a significant impact on the effective income tax rate for fiscal year ended September 30, 2021, as taxable income was decreased by $9.8 million.

Per diem paid to employees on construction projects and entertainment expenses are only partially deductible from taxable income and can have a significant impact on the effective tax rate. For the fiscal years ended September 30, 2021, and 2020, the non-deductible portion of per diem and entertainment expenses resulted in an approximate increase in taxable income of $515,000 and $530,000, respectively.

Dividends on preferred stock for fiscal years ended September 30, 2021, and 2020 were $284,238 and $309,000, respectively. There will be no further dividends paid on preferred stock after the October 6, 2021 redemption of all the Company’s preferred stock.

Net income available to common shareholders for fiscal year ended September 30, 2021, was $8.8 million compared to $2.1 million for fiscal year ended September 30, 2020.

Table of Contents

Comparison of Financial Condition at September 30, 2021 Compared to September 30, 2020.

The Company had total assets of $70.2 million at September 30, 2021, an increase of $12.0 million from the prior fiscal year end balance of $58.2 million.

Net property, plant and equipment totaled $22.9 million at September 30, 2021, an increase of $6.5 million from the prior fiscal year end balance of $16.4 million. Property, plant and equipment acquisitions totaled $11.3 million for fiscal year 2021 while depreciation expense was $4.7 million, and the net impact of disposals was $76,000. Assets received as part of the West Virginia Pipeline and Revolt Energy acquisitions accounted for $2.1 million of the $11.3 million in total acquisitions.

Goodwill and acquired intangible assets resulting from the West Virginia Pipeline and Revolt Energy acquisitions totaled $4.2 million at September 30, 2021, as compared to no goodwill and acquired intangible assets at the prior fiscal year end.

Contract assets totaled $8.7 million at September 30, 2021, an increase of $2.2 million from the prior fiscal year end balance of $6.5 million. This increase was primarily due to the timing of project billings and related increase in costs and estimated earnings in excess of billings at September 30, 2021 as compared to at September 30, 2020.

The aggregate balance of accounts receivable, retainages receivable, allowance for doubtful accounts and other receivables totaled $22.5 million at September 30, 2021, an increase of $1.8 million from the combined prior fiscal year end balance of $20.7 million. The increase was primarily due to a $2.5 million increase in accounts receivable related to the new subsidiaries, West Virginia Pipeline and SQP.

Prepaid expenses and other totaled $3.5 million at September 30, 2021, an increase of $200,000 from the prior fiscal year end balance of $3.3 million. The increase was primarily due to the increase of various prepaid insurance accounts based on labor cost expensed or standard monthly charges.

Cash and cash equivalents totaled $8.2 million at September 30, 2021, a decrease of $3.0 million from the prior fiscal year end balance of $11.2 million. The decrease was primarily related to a $6.0 million investment in property and equipment and $2.8 million in long-term debt repayments, partially offset by a $4.5 million increase in line of credit borrowings and $800,000 net cash provided by operating activities.

Liabilities totaled $35.5 million at September 30, 2021, an increase of $3.2 million from the prior fiscal year end balance of $32.3 million.

Lines of credit and short-term borrowings totaled $5.0 million at September 30, 2021, an increase of $4.5 million from the prior fiscal year end balance of $510,000. This increase was primarily due to borrowings against the Company’s operating line of credit.

Accounts payable totaled $7.3 million as of September 30, 2021, an increase of $2.1 million from the prior fiscal year end balance of $5.2 million. The increase was due to the timing of payments to material and equipment providers. New subsidiaries, West Virginia Pipeline and SQP, accounted for $1.1 million of the increase.

Accrued expenses and other current liabilities totaled $5.6 million at September 30, 2021, an increase of $1.4 million from the prior fiscal year end balance of $4.2 million. The increase was primarily due to increased labor and burden expenses incurred towards the end of fiscal year 2021 compared to 2020.

The aggregate balance of current maturities of long-term debt and long-term debt totaled $12.4 million at September 30, 2021, a decrease of $2.8 million from the prior fiscal year end balance of $15.3 million. The decrease was primarily due to forgiveness received on $9.8 million in PPP loans and $2.8 million in debt repayments, partially offset by a $6.4 million increase related to financing the West Virginia Pipeline acquisition and a $3.0 million increase related to the financing of equipment.

Contract liabilities totaled $3.2 million at September 30, 2021, a decrease of $1.7 million from the prior fiscal year end balance of $4.9 million. This decrease was due to a lower amount of overbillings when comparing the billed revenue and percentage of cost completed on construction projects in 2021 as compared to 2020.

Table of Contents

Net deferred income tax payable totaled $2.0 million at September 30, 2021, a decrease of $222,000 from the prior fiscal year end balance of $2.3 million. The decrease was primarily due to a loss from operations net of non-taxable income recognized from PPP loan forgiveness and deferred income tax payable resulting from bonus depreciation on property, plant and equipment acquisitions in fiscal year 2021.

Shareholders’ equity totaled $34.6 million at September 30, 2021, an increase of $8.8 million from the prior fiscal year end balance of $25.8 million. This increase was primarily due to $9.8 million in income related to PPP loan forgiveness, partially offset by a loss of ($742,000) prior to PPP loan forgiveness, and $284,000 in accrued preferred dividends.

Liquidity and Capital Resources

Indebtedness

Table of Contents

Operating Line of Credit

On August 3, 2021, the Company received a one-year extension on its line of credit (“Operating Line of credit (2021)”) effective June 28, 2021. The $15.0 million revolving line of credit has a $12.5 million component and a $2.5 million component, each with separate borrowing requirements. The interest rate on the line of credit is the “Wall Street Journal” Prime Rate (the index) with a floor of 4.99%. Based on the borrowing base calculation, the Company was able to borrow up to $12.2 million as of September 30, 2021. The Company had $4.5 million in borrowings on the line of credit, leaving $7.7 million available on the line of credit as of September 30, 2021. The interest rate at September 30, 2021, was 4.99%. Based on the borrowing base calculation, the Company was able to borrow up to $11.1 million as of September 30, 2020. The Company had no borrowings on the line of credit, as of September 30, 2020. The interest rate at September 30, 2020, was 4.99%.

Major items excluded from the borrowing base calculation are receivables from bonded jobs and retainage as well as all items greater than ninety (90) days old. Line of credit borrowings are collateralized by the Company’s accounts receivable. Cash available under the line is calculated based on 70.0% of the Company’s eligible accounts receivable.

Under the terms of the agreement, the Company must meet the following loan covenants to access the first $12.5 million:

1. Minimum tangible net worth of $19.0 million to be measured quarterly,

3. Minimum current ratio of 1.50x to be measured quarterly,

Under the terms of the agreement, the Company must meet the following additional requirements for draw requests causing the borrowings to exceed $12.5 million:

2. Minimum tangible net worth of $21.0 million to be measured quarterly.

The Company was in compliance with all covenants for the $12.5 million component of Operating Line of Credit (2021) at September 30, 2021 except for the debt service coverage ratio, for which the Company obtained a waiver from its lender.

As of September 30, 2021, the Company had $8.2 million in cash and $18.4 million in working capital. The maturities of long-term and short-term debt, which includes line of credit borrowings, term notes payable to banks, and notes payable on various equipment purchases, were as follows:

Table of Contents

Off-Balance Sheet Transactions

Due to the nature of our industry, we often enter into certain off-balance sheet arrangements in the ordinary course of business that result in risks not directly reflected on our balance sheets. Though for the most part not material in nature, some of these are:

Leases

In February 2016, the FASB issued ASU 2016-02, “Leases (Topic 842)”. ASU 2016-02 is effective for public business entities for fiscal years beginning after December 15, 2018, including interim periods within those fiscal years. Among other things, lessees are required to recognize the following for all leases (except for short-term leases) at the commencement date: a lease liability, which is a lessee’s obligation to make lease payments arising from a lease, measured on a discounted basis; and a right-of-use asset, which is an asset that represents the lessee’s right to use, or control the use of, a specified asset for the lease term. It is the Company’s preference to acquire equipment needed for long-term use through purchase, by cash or finance. For equipment needed on a short-term basis, the Company will enter into short-term rental agreements with the equipment provider where the agreement is cancellable at any time. The adoption of ASU 2016-02 had an immaterial impact, if any, on its consolidated financial statements.

The Company leases office space for SQP Construction Group for $1,500 per month. The lease, signed on March 25, 2021, is for a period of two years with five one-year renewals available immediately following the end of the base term. Rental terms for the option periods shall be negotiated and agree mutually between the parties and shall not exceed five percent increases to rent, if any. The lease is expensed monthly and not treated as a right-to-use asset as it does not have a material impact on the Company’s consolidated financial statements.

The Company rents equipment for use on construction projects with rental agreements being week to week or month to month. Rental expense can vary by fiscal year due to equipment requirements on construction projects and the availability of Company owned equipment. Rental expense, which is included in cost of goods sold on the Consolidated Income Statement, was $3.6 million and $4.2 million for the twelve months ended September 30, 2021, and 2020, respectively.

Letters of Credit

Certain of our customers or vendors may require letters of credit to secure payments that the vendors are making on our behalf or to secure payments to subcontractors, vendors, etc. on various customer projects. At September 30, 2021, the Company did not have any outstanding letters of credit.

Performance Bonds

Some customers, particularly new ones or governmental agencies require the Company to post bid bonds, performance bonds and payment bonds (collectively, performance bonds). These bonds are obtained through insurance carriers and guarantee to the customer that we will perform under the terms of a contract and that we will pay subcontractors and vendors. If the Company fails to perform under a contract or to pay subcontractors and vendors, the customer may demand that the insurer make payments or provide services under the bond. The Company must reimburse the insurer for any expenses or outlays it is required to make.

Currently, the Company has an agreement with a surety company to provide bonding which will suit the Company’s immediate needs. The ability to obtain bonding for future contracts is an important factor in the contracting industry with respect to the type and value of contracts that can be bid. Depending upon the size and conditions of a particular contract, the Company may be required to post letters of credit or other collateral in favor of the insurer. Posting of these letters or other collateral will reduce our borrowing capabilities. The Company does not anticipate any claims in the foreseeable future. At September 30, 2021, the Company had $30.1 million in performance bonds outstanding.

Concentration of Credit Risk

In the ordinary course of business, the Company grants credit under normal payment terms, generally without collateral, to our customers, which include natural gas and oil companies, general contractors, and various commercial and industrial customers located within the United States. Consequently, the Company is subject to potential credit risk related to business and economic factors that would affect these companies. However, the Company generally has certain statutory lien rights with respect to services provided.

Table of Contents

Under certain circumstances such as foreclosure, the Company may take title to the underlying assets in lieu of cash in settlement of receivables.

Please see the tables below for customers that represent 10.0% or more of the Company’s revenue or accounts receivable net of retention for the fiscal years ended September 30, 2021, and 2020:

TransCanada Corporation 11.0 % 24.7 %

Marathon Petroleum * 11.1 %

* Less than 10.0% and included in "All other" if applicable

Accounts receivable net of retention FY 2021 FY 2020

Kentucky American Water 16.3 % *

TransCanada Corporation 13.2 % 18.4 %

Marathon Petroleum * 19.7 %

Shimizu North American LLC * 11.9 %

* Less than 10.0% and included in "All other" if applicable

Virtually all work performed for major customers was awarded under competitive bid fixed price or unit price arrangements. The loss of a major customer could have a severe impact on the profitability of operations of the Company. However, due to the nature of the Company’s operations, the major customers and sources of revenues may change from year to year.

Litigation

In February 2018, the Company filed a lawsuit against a former customer (“Defendant”) in the United States District Court for the Western District of Pennsylvania. The lawsuit is related to a dispute over changes on a pipeline construction project. On November 9, 2021, the Company was awarded $5.8 million, none of which has been recognized in the Company’s financial statements. The Defendant has filed motions to request a new trial or a renewed judgement as a matter of law, which has not been ruled upon. The Company anticipates that a final judgement order will be issued in the first calendar quarter of 2022. A party to a civil lawsuit usually has 30 days from the entry of judgment to file a notice of appeal.

Related Party Transactions

We intend that all transactions between us and our executive officers, directors, holders of 10% or more of the shares of any class of our common stock and affiliates thereof, will be on terms no less favorable than those terms given to unaffiliated third parties and will be approved by a majority of our independent outside directors not having any interest in the transaction.

On December 16, 2014, the Company’s Nitro subsidiary entered into a 20-year $1.2 million loan agreement with First Bank of Charleston, Inc. (West Virginia) to purchase the office building and property it had previously been leasing for $6,300 each month. The interest rate on the loan agreement is 4.82% with monthly payments of $7,800. As of September 30, 2021, the Company had paid approximately $281,000 in principal and approximately $351,000 in interest since the beginning of the loan. Mr. Douglas Reynolds,

Table of Contents

President of Energy Services, was a director and secretary of First Bank of Charleston. Mr. Samuel Kapourales, a director of Energy Services, was also a director of First Bank of Charleston. On October 15, 2018, First Bank of Charleston was merged into Premier Bank, Inc., a wholly owned subsidiary of Premier Financial Bancorp, Inc. Mr. Marshall Reynolds, Chairman of the Board of Energy Services, held the same position with Premier Financial Bancorp Inc. Mr. Douglas Reynolds is the president and a director of Energy Services and was a director of Premier Financial Bancorp, Inc. On September 17, 2021, Peoples Bancorp, Inc., parent company of Peoples Bank, completed an acquisition of Premier Financial Bancorp, Inc. and its wholly owned subsidiaries, Premier Bank and Citizens Deposit Bank & Trust. On October 26, 2021, Mr. Douglas Reynolds was elected a director of Peoples Bancorp, Inc., and its subsidiary Peoples Bank.

Other than mentioned above, there were no new material related party transactions entered into during the fiscal year ended September 30, 2021.

Certain Energy Services subsidiaries routinely engage in transactions in the normal course of business with each other, including sharing employee benefit plan coverage, payment for insurance and other expenses on behalf of other affiliates, and other services incidental to business of each of the affiliates. All revenue and related expense transactions, as well as the related accounts payable and accounts receivable have been eliminated in consolidation.

Inflation

Most significant project materials, such as pipe or electrical wire, are provided by the Company’s customers. Therefore, inflation did not have a significant effect on our results for the fiscal years ended September 30, 2021, and 2020. However, significant inflation or supply chain issues could cause customers to delay or cancel planned projects.

Critical Accounting Estimates

The discussion and analysis of the Company’s financial condition and results of operations are based on our consolidated financial statements, which have been prepared in accordance with accounting principles generally accepted in the United States. The preparation of these consolidated financial statements requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities, disclosures of contingent assets and liabilities known to exist at the date of the consolidated financial statements and reported amounts of revenues and expenses during the reporting period. We evaluate our estimates on an ongoing basis, based on historical experience and on various other assumptions that are believed to be reasonable under the circumstances. There can be no assurance that actual results will not differ from those estimates. Management believes the following accounting policies affect our more significant judgments and estimates used in the preparation of our consolidated financial statements.

Revenues

The Company recognizes revenue as performance obligations are satisfied and control of the promised good and service is transferred to the customer. For Lump Sum and Unit Price contracts, revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward complete satisfaction of the performance obligation(s) using an input (i.e., “cost to cost”) method. For Cost Plus and Time and Material (“T&M”) contracts, revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward satisfaction of the performance obligation(s) using an output method. The Company also does certain T&M service work that is generally completed in a short duration and is recognized at a point in time.

Table of Contents

The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our estimates of the cost to complete each project. We believe our experience allows us to create materially reliable estimates. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include:

● the completeness and accuracy of the original bid;

● costs associated with scope changes;

● changes in costs of labor and/or materials;

● extended overhead and other costs due to owner, weather and other delays;

● subcontractor performance issues;

● changes in productivity expectations;

● site conditions that differ from those assumed in the original bid;

● changes from original design on design-build projects;

● a change in the availability and proximity of equipment and materials;

● the customer’s ability to properly administer the contract.

The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins may cause fluctuations in gross profit from period to period. Significant changes in cost estimates, particularly in our larger, more complex projects could have, a significant effect on our profitability.

Our contract assets include cost and estimated earnings in excess of billings that represent amounts earned and reimbursable under contracts, including claim recovery estimates, but have a conditional right for billing and payment such as achievement of milestones or completion of the project. With the exception of customer affirmative claims, generally, such unbilled amounts will become billable according to the contract terms and generally will be billed and collected over the next three months. Settlement with the customer of outstanding affirmative claims is dependent on the claims resolution process and could extend beyond one year. Based on our historical experience, we generally consider the collection risk related to billable amounts to be low. When events or conditions indicate that it is probable that the amounts outstanding become unbillable, the transaction price and associated contract asset is reduced.

Our contract liabilities consist of provisions for losses and billings in excess of costs and estimated earnings. Provisions for losses are recognized in the consolidated statements of income at the uncompleted performance obligation level for the amount of total estimated losses in the period that evidence indicates that the estimated total cost of a performance obligation exceeds its estimated total revenue. Billings in excess of costs and estimated earnings are billings to customers on contracts in advance of work performed, including advance payments negotiated as a contract condition. Generally, unearned project-related costs will be earned over the next twelve months.

The following table presents our costs and estimated earning in excess of billings and billings in excess of costs and estimated earnings at September 30, 2021, and 2020:

Year Ended September 30,

Costs and estimated earnings in excess of billed on

Less billings in excess of costs and estimated earnings on

Table of Contents

Allowance for doubtful accounts

The Company provides an allowance for doubtful accounts when collection of an account is considered doubtful. Inherent in the assessment of the allowance for doubtful accounts are certain judgments and estimates relating to, among others, our customers’ access to capital, our customers’ willingness or ability to pay, general economic conditions and the ongoing relationship with the customers. While most of our customers are large well capitalized companies, should they experience material changes in their revenues and cash flows or incur other difficulties and not be able to pay the amounts owed, this could cause reduced cash flows and losses in excess of our current reserves.

Materially incorrect estimates of bad debt reserves could result in an unexpected loss in profitability for the Company. Additionally, frequently changing reserves could be an indication of risky or unreliable customers. At September 30, 2021, the management review deemed that the allowance for doubtful accounts was adequate. Please see the table below:

Year Ended September 30,

Charged to expense — —

Deductions for uncollectible receivables written off, net of recoveries — —

Impairment of goodwill and intangible assets

The Company follows the guidance of ASC 350-20-35-3 Intangibles-Goodwill and Other (Topic 350) which requires a company to record an impairment charge based on the excess of a reporting unit’s carrying amount of goodwill over its fair value. Under the current guidance, companies can first choose to assess any impairment based on qualitative factors (Step 0). If a company fails this test or decides to bypass this step, it must proceed with a two-step quantitative assessment of goodwill impairment. The Company did not have a goodwill impairment at September 30, 2021.

Based on management's preliminary valuation of tangible and intangible assets acquired and liabilities assumed, the West Virginia Pipeline and Revolt Energy acquisitions resulted in goodwill of $4.2 million and intangible assets of $400,000. A subsequent independent, third-party fair value evaluation analysis of the purchase price allocations resulted in the reclassification of $2.3 million from goodwill to intangible assets, primarily customer relationships. At September 30, 2021, goodwill and intangible assets were $1.8 million and $2.4 million, respectively.

Materially incorrect estimates could cause an impairment to goodwill or intangible assets and result in a loss in profitability for the Company.

A table of the Company’s intangible assets subject to amortization is below:

Remaining Life at Amortization and

September 30, Original Accumulated Impairment FY Net Book

Intangible assets: 2021 Cost Amortization 2021 Value

West Virginia Pipeline

Revolt Energy

Table of Contents

Depreciation

The purpose of depreciation is to represent an accurate value of assets on the books. Every year, as assets are used, their values are reduced on the balance sheet and expensed on the income statement. As depreciation is a noncash expense, the amount must be estimated. Each year a certain amount of depreciation is written off and the book value of the asset is reduced.

Property and equipment are recorded at cost. Costs which extend the useful lives or increase the productivity of the assets are capitalized, while normal repairs and maintenance that do not extend the useful life or increase productivity of the asset are expensed as incurred. Property and equipment are depreciated principally on the straight-linemethod over the estimated useful lives of the assets: buildings 39 years; operating equipment and vehicles 5-7 years; and office equipment, furniture and fixtures 5-7 years.

The Company’s depreciation expense for fiscal years ended September 30, 2021, and 2020 was $4.7 million and $4.4 million, respectively. In general, depreciation is included in “cost of revenues” on the Company’s Consolidated Statements of Income.

Materially incorrect estimates of depreciation and/or the useful lives of assets could significantly impact the value of property, plant, and equipment on the Company’s financial statements. A material over valuation could result in impairment charges and reduced profitability for the Company.

Income Taxes

Our income tax expense and deferred tax assets and liabilities reflect management’s best estimate of current and future taxes to be paid. Significant judgments and estimates are required in the determination of the consolidated income tax expense. The Company’s provision for income taxes is computed by applying a federal rate of 21.0% and a state rate of 6.0%.

Permanent income tax differences result in an increase or decrease to taxable income and impact the Company’s effective tax rates, which were (.32%) and 32.0% for fiscal years 2021 and 2020, respectively. Our tax rate is affected by recurring items, such as non-tax deductible portions of per diem paid to construction personnel, which we expect to be fairly consistent in the near term. For the fiscal years ended September 30, 2021, and 2020, the non-deductible portion of per diem and entertainment expenses resulted in approximate increases in taxable income of $515,000 and $530,000, respectively. Our tax estimates are also affected by discrete items that may occur in any given year but are not consistent from year to year. In fiscal year 2021, $9.8 million in PPP loan forgiveness was excluded from taxable income. Additionally, the Company is expecting to receive approximately a $250,000 federal income tax credit related to a solar installation project at its Nitro, WV facility.

Deferred income taxes arise from temporary differences between the tax basis of assets and liabilities and their reported amounts in the financial statements, which will result in taxable or deductible amounts in the future. At September 30, 2021, the Company had a net deferred income tax liability of $2.0 million as compared to $2.3 million at September 30, 2020. The Company’s deferred income tax liabilities at September 30, 2021 was $4.9 million and primarily related to depreciation on property and equipment. The Company’s deferred income tax assets at September 30, 2021 was $2.9 million and primarily related to a net operating loss (“NOL”) carryforward. The Company believes that it is more likely than not that all NOL carryforwards will be realized.

The Company’s tax provision is evaluated as part of its annual audit; however, a material difference between the provision and actual income tax filings could result in adjustments to income tax benefits or expenses and deferred tax assets and liabilities. Changes in tax laws and rates may also affect recorded deferred tax assets and liabilities and our effective tax rate in the future.

New Accounting Pronouncements

In January 2017, the FASB issued ASU 2017-04, “Intangibles-Goodwill and Other (Topic 350): Simplifying the Test for Goodwill Impairment”. ASU 2017-04 is effective for public business entities for fiscal years beginning after December 15, 2019, including interim periods within those fiscal years. The update was issued to simplify the subsequent measurement of goodwill by eliminating Step 2 from the goodwill impairment test. Under the amendments in this Update, an entity should perform its annual, or interim, goodwill impairment test by comparing the fair value of a reporting unit with its carrying amount. An entity should recognize an impairment charge for the amount by which the carrying amount exceeds the reporting unit’s fair value; however, the loss recognized should not exceed the total amount of goodwill allocated to that reporting unit. Additionally, an entity should consider income tax effects from any tax-deductible goodwill on the carrying amount of the reporting unit when measuring the goodwill impairment loss, if applicable. The Company has adopted ASU 2017-04 and it did not have a material impact on its financial statements or disclosure.

Table of Contents

On October 28, 2021, the FASB released ASU 2021-08, “Business Combinations (Topic 805): Accounting for Contract Assets and Contract Liabilities from Contracts with Customers”. The amendments of this ASU require entities to apply Topic 606 to recognize and measure contract assets and contract liabilities in a business combination. The amendments improve comparability after the business combination by providing consistent recognition and measurement guidance for revenue contracts with customers acquired in a business combination and revenue contracts with customers not acquired in a business combination. The amendments are effective for public business entities for fiscal years, including interim periods within those fiscal years, beginning after December 15, 2022. For all other entities they are effective for fiscal years, including interim periods within those fiscal years, beginning after December 15, 2023. Entities should apply the amendments prospectively to business combinations that occur after the effective date. Early adoption is permitted, including in any interim period, for public business entities for periods for which financial statements have not yet been issued, and for all other entities for periods for which financial statements have not yet been made available for issuance.

Subsequent Events

On October 6, 2021, the Company’s transfer agent completed the previously disclosed Series A Preferred Stock redemption, which resulted in the issuance of 2,626,492 new shares of the Company’s common stock, the issuance of 317,500 common shares that were included in Series A Preferred Stock units, and cash redemption payments of approximately $1.3 million. The Company’s total outstanding common shares after redemption was 16,247,898 as of October 6, 2021.

On November 9, 2021, the Company was awarded $5.8 million in a lawsuit related to construction services performed for a former customer (“Defendant”), none of which has been recognized in the Company’s financial statements. The Defendant has filed motions to request a new trial or a renewed judgement as a matter of law, which has not been ruled upon. The Company anticipates that a final judgement order will be issued in the first calendar quarter of 2022. A party to a civil lawsuit usually has 30 days from the entry of judgment to file a notice of appeal.

On November 12, 2021, the Company received a withdrawal liability claim from a pension plan to which the Company made pension contributions for union construction employees performing covered work in a particular jurisdiction. The Company has not performed covered work in their jurisdiction since 2011; however, the Company disagrees with the withdrawal claim and believes it is covered by an exemption under federal law. The demand called for thirty-four quarterly installment payments of $41,000 starting December 15, 2021. The Company must comply with the demand under federal pension law; however, the Company firmly believes no withdrawal liability exists and plans to seek arbitration to resolve the matter. If successfully arbitrated, the Company expects to receive repayment of all installment payments made.

Management has evaluated subsequent events through December 29, 2021, the date which the financial statements were available for issue. There have been no material events noted during the period that would either impact the results reflected in this report or the Company’s results going forward.

ITEM 7A. Quantitative and Qualitative Disclosures about Market Risk

Not required for smaller reporting companies.

ITEM 8.Financial Statements and Supplementary Data

Financial Statements are included at page F-1 of this Annual Report on Form 10-K.

ITEM 9.Changes in and Disagreements with Accountants on Accounting and Financial Disclosure

None.

ITEM 9A.Controls and Procedures

(a) Evaluation of Disclosure Controls and Procedures

Under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer, the Company evaluated the effectiveness of the design and operation of our disclosure controls and procedures (as defined in

Table of Contents

Rule 13a-15(e) under the Securities Exchange Act of 1934) as of the end of the period covered by this report. Based upon that evaluation, the Chief Executive Officer and Chief Financial Officer concluded that, as of the end of the period covered by this report, our disclosure controls and procedures were effective to ensure that information required to be disclosed in the reports that Energy Services files or submits under the Securities Exchange Act of 1934 is recorded, processed, summarized and reported, within the time periods specified in the SEC’s rules and forms.

(b) Management’s Report on Internal Control over Financial Reporting

Management is responsible for establishing and maintaining adequate internal control over financial reporting for the Company. Internal control over financial reporting refers to the process designed by, or under the supervision of, our Chief Executive Officer and Chief Financial Officer, and effected by our Board of Directors, management and other personnel, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles, and includes those policies and procedures that:

(1) Pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the Company;

(2) Provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the Company are being made only in accordance with authorizations of management and directors of the Company; and

(3) Provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use or disposition of the Company’s assets that could have a material effect on the Company’s financial statements.

Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.

Management has used the framework set forth in the report entitled “Internal Control–Integrated Framework 2013” published by the Committee of Sponsoring Organizations of the Treadway Commission to evaluate the effectiveness of the Company’s internal control over financial reporting. Management has not identified any material weakness in the Company’s internal control over financial reporting. Management has concluded that the Company’s internal control over financial reporting was effective as of the end of the most recent fiscal year.

This Annual Report does not include an attestation report of the Company’s independent registered public accounting firm regarding internal control over financial reporting. Management’s report was not subject to attestation by the Company’s independent registered public accounting firm pursuant to rules of the SEC that permit the Company to provide only Management’s report in this Annual Report.

There has been no change in Energy Services of America Corporation’s internal control over financial reporting during Energy Services of America Corporation’s fourth quarter of fiscal year 2021, that has materially affected, or is reasonably likely to materially affect, Energy Services of America Corporation’s internal control over financial reporting.

ITEM 9B.Other Information

None.

ITEM 9C.Disclosure Regarding Foreign Jurisdictions that Prevent Inspections.

Not Applicable.

Table of Contents

PART III

ITEM 10.Directors, Executive Officers and Corporate Governance

The principal occupation during the past five years of each director and executive officer is set forth below. All directors and executive officers have held their present positions since our inception in 2006 unless otherwise stated.

Marshall T. Reynolds has served as Chairman of the Board of Directors since our inception. Mr. Reynolds has served as Chief Executive Officer and Chairman of the Board Directors of Champion Industries, Inc., a commercial printer, business form manufacturer and supplier of office products and furniture, from 1992 to 2016, and sole stockholder from 1972 to 1993; President and General Manager of The Harrah and Reynolds Corporation, from 1964 (and sole stockholder since 1972) to present; and Chairman of the Board of Directors of McCorkle Machine and Engineering Company in Huntington, West Virginia. Mr. Reynolds is also Chairman of the Board of Directors of First Guaranty Bancshares, Inc., in Hammond, Louisiana, a director of Summit State Bank in Santa Rosa, CA since December 1998, and was Chairman of Premier Financial Bancorp, Inc. in Huntington, WV from 2011 to 2021. Mr. Reynolds is the father of Jack M. Reynolds and Douglas V. Reynolds. Mr. Reynolds varied career as a business leader and experience in a number of industries qualifies him to be on the Board of Directors.

Douglas V. Reynolds was appointed President and Chief Executive Officer of the Company on December 6, 2012, and has served as a Director since 2008. Mr. Reynoldsis an attorney for Reynolds & Brown, PLLC. Mr. Reynolds is the President of the Transylvania Corporation and a director of The Harrah and Reynolds Corporation and Peoples Bancorp, Inc. and its banking subsidiary Peoples Bank beginning in 2021. Mr. Reynolds was a director of Premier Financial Bancorp, Inc. from 2020 to 2021. Mr. Reynolds is a graduate of Duke University and holds a law degree from West Virginia University. Mr. Reynolds is the son of Director Marshall T. Reynolds and brother of Jack M. Reynolds. Mr. Reynolds’ varied experience and senior management roles with other companies make Mr. Reynolds a valuable member of the Board.

Jack M. Reynoldsserved as President and Chief Financial Officer from our inception until September 2008 and has been a member of our Board of Directors since our inception. Mr. Reynolds has been a Vice President of Pritchard Electric Company since 1998. Pritchard is an electrical contractor providing electrical services to both utility companies as well as private industries. Mr. Reynolds also serves as a Director of Citizens Deposit Bank of Vanceburg, Kentucky. Mr. Reynolds is the son of Marshall T. Reynolds and the brother of Douglas V. Reynolds. Mr. Reynolds lengthy service at Pritchard Electric and knowledge of the contracting industry provides hands on expertise to the Board of Directors.

Joseph L. Williams has been a Director since our inception. Mr. Williams is the Chairman and Chief Executive Officer of Basic Supply Company, Inc., which he founded in 1977. Mr. Williams was Chairman, President and Chief Executive Officer of Consolidated Bank & Trust Co., in Richmond, Virginia from 2007 until it merged with Premier Financial Bancorp, Inc. in 2009. Mr. Williams is a former member of the West Virginia Governor’s Workforce Investment Council. He is a former Director of Unlimited Future, Inc. (a small business incubator) and a former Member of the National Advisory Council of the U.S. Small Business Administration. Mr. Williams is a former Mayor and City Councilman of the City of Huntington, West Virginia. He is a graduate of Marshall University with a degree in finance and is a former member of its Institutional Board of Governors. Mr. Williams' investment and management experience provides the board of directors an important perspective in business development.

Samuel G. Kapourales was appointed to the Board of Directors on December 20, 2010. He is a Board Member of the West Virginia Health Care Authority and Kapourales Properties, LLC. Mr. Kapourales serves as a Director of First National Bank of Williamson. Mr. Kapourales’ varied business experience makes him a valuable member of the Board.

Charles Abraham, MD was appointed to the Board of Directors on January 1, 2016. Dr. Abraham is a retired Otolaryngology (Ear Nose & Throat) Specialist in Huntington, WV and was affiliated with multiple hospitals in the area, including Cabell Huntington Hospital and St. Mary’s Medical Center. Dr. Abraham continues to practice part-time at the Veterans Affairs Medical Center. He received his medical degree from West Virginia University School of Medicine and has been in practice since 1968. He also received an MBA degree from Marshall University in August 1996. Dr. Abraham is certified by the American Board of Otolaryngology. Dr. Abraham’s healthcare experience and understanding of health insurance related matters makes him a valuable member of the Board.

Frank Lucente was appointed to the Board of Directors on June 19, 2019. Mr. Lucente, a retired Naval officer, holds a Master’s in Business Administration (MBA) with a specialty in marketing from Marshall University in Huntington, WV. Mr. Lucente is the founder, owner and president of Sam’s Hot Dogs, Inc., a franchise with over 45 locations in Virginia, West Virginia, Kentucky, North

Table of Contents

Carolina, and Georgia. In addition, Mr. Lucente is the co-founder of Rocco’s Restaurants, Inc. in Ceredo, WV. From 2005 to 2016, Mr. Lucente served as a city council member in Waynesboro, VA and served stints as vice mayor and mayor during that time. Mr. Lucente has served as the chairman of the board of Rocco’s Italian Specialty Foods, Inc. since 2014.Mr. Lucente’s business experience makes him a valuable member of the Board.

Daniel Mannes was appointed to the Board of Directors on October 21, 2020. Mr. Mannes has held the position of Vice President of Investor Relations at Covanta Holding Corporation, Morristown, NJ, since 2016. Previously, Mr. Mannes had held various corporate finance positions since 1996. Mr. Mannes, a Chartered Financial Analyst (CFA), earned a Master of Business Administration (MBA) degree with a concentration in finance from the University of Maryland, Baltimore, Maryland, in 2004. Previously, Mr. Mannes earned a Bachelor of Science in Business Administration (BSBA) degree majoring in accounting/finance from Washington University, St. Louis, Missouri, in 1996. Mr. Mannes’ finance and investor relations experience provides insight to issues important to stockholders and investors.

Brian Pratt was appointed to the Board of Directors on August 18, 2021. Mr. Pratt has over 35 years of hands-on operations and management experience in the construction industry. From 1983 through 2015, he served as the President, Chief Executive Officer and Chairman of the Board of Primoris Services Corp. and its predecessor entity, ARB, Inc. Mr. Pratt served as Chairman of Primoris Services Corp. from 2008 until 2019 and as a Director until February 2020. Mr. Pratt’s experience in the construction industry as well as mergers and acquisitions make him a valuable member of the board.

Charles P. Crimmel was appointed as Chief Financial Officer of the Company on November 1, 2013, after serving as Controller from 2008 to 2013. Mr. Crimmel graduated from West Virginia University in 1995 with a Bachelor of Science degree in Business Administration and Accounting. Mr. Crimmel was employed by Union Boiler Company as a Field Clerk and Staff Accountant from 1995 to 1996. From 1996-2005, Mr. Crimmel served as Staff Accountant and Controller for Williams Union Boiler/Williams Service Group. From 2005-2008, Mr. Crimmel was Controller for Nitro Electric Company.

Board Leadership Structure and Risk Oversight

Our board of directors is chaired by Mr. Marshall T. Reynolds, who is a non-executive director. We separate the roles of Chief Executive Officer and Chairman of the Board in recognition of the differences between the two roles. The Chief Executive Officer is responsible for overseeing the day-to-day operations of the Company. The Chairman provides guidance to the Chief Executive Officer and, together with the entire board of directors helps develop the strategic plan for the Company.

The role of the board of directors in the Company’s risk oversight process includes receiving reports from senior management on areas of material risk to the Company, including operational, financial, legal, regulatory, strategic and reputational risk. The full board reviews such reports and follows up with senior management to best determine how to address such risks.

Delinquent Section 16(a) Reports

The Company did not have any delinquent filings in fiscal year 2021.

Meetings of the Board of Directors

During fiscal 2021, the Board of Directors held twelve regular meetings and three special meetings. Two directors, Dr. Charles Abraham and Mr. Neal Scaggs, attended fewer than 75% in the aggregate of the total number of board and committee meetings. Although not required, attendance of Board members at the Annual Meeting of Shareholders is encouraged. All members of our Board of Directors as of the Annual Meeting date attended the 2021 Annual Meeting of Shareholders.

Board Committees

Audit Committee. The Audit Committee consists of Messrs. Mannes, Lucente, and Kapourales, with Mr. Mannes acting as chairman of the committee since December 16, 2020. Mr. Scaggs was an audit committee member until his death on November 7, 2021. Mr. Kapourales was subsequently appointed to the committee. Each member of the audit committee is financially literate, and the Board of Directors has determined that Mr. Mannes qualified as audit committee financial expert, as such term is defined by Securities and Exchange Commission rules.All the directors appointed to the audit committee are independent members of the board of directors, as defined by Securities and Exchange Commission rules (Rule 10A-3 of the Securities Exchange Act of 1934) and the NYSE American

Table of Contents

corporate governance listing standards. The audit committee met three times during the fiscal year ended September 30, 2021. The committee’s charter can be found at: www.energyservicesofamerica.com/posting/Audit_Committee_Charter_v1.pdf.

The Audit Committee reviews the professional services and independence of our independent registered public accounting firm and our accounts, procedures and internal controls. The audit committee also recommends the firm selected to be our independent registered public accounting firm, reviews and approves the scope of the annual audit, reviews and evaluates with the independent registered public accounting firm our annual audit and annual consolidated financial statements, reviews with management the status of internal accounting controls, evaluates problem areas having a potential financial impact on us that are brought to the committee’s attention by management, the independent registered public accounting firm or the board of directors, and evaluates all of our public financial reporting documents.

On November 1, 2021, Baker Tilly, US, LLP (“Baker Tilly”) completed the acquisition of the Company’s independent registered public accounting firm, Arnett Carbis Toothman, LLP. The Audit Committee approved the appointment of Baker Tilly, US, LLP (“Baker Tilly”) to be our independent registered public accounting firm effective November 1, 2021, and for the 2022 fiscal year. A representative of Baker Tilly is expected to attend the 2022 Annual Meeting of Stockholders.

Nominating Committee. The Board has determined that the independent members of the Board of Directors will perform the duties of the nominating committee of the Board of Directors. The nominating committee does not have a written charter. The nominating committee will (i) identify individuals qualified to become members of the Board of Directors and recommend to the Board of Directors the nominees for election to the Board of Directors; (ii) recommend director nominees for each committee to the Board of Directors; and (iii) identify individuals to fill any vacancies on the Board of Directors. The nominating committee met one time during the fiscal year ended September 30, 2021.

The nominating committee of the Board identifies nominees by first evaluating the current members of the Board of Directors willing to continue in service. Current members of the Board of Directors with skills and experience that are relevant to our business and who are willing to continue in service are first considered for re-nomination, balancing the value of continuity of service by existing members of the Board of Directors with that of obtaining a new perspective. If any member of the Board of Directors does not wish to continue in service, or if the Board decides not to re-nominate a member for re-election, or if the size of the Board of Directors is increased, the independent directors would solicit suggestions for director candidates from all board members. The independent directors would seek to identify a candidate who at a minimum satisfies the following criteria:

The nominating committee will also consider whether a candidate satisfies the criteria for “independence” under Securities and Exchange Commission or NYSE American rules and, if a nominee is sought for service on the audit committee, the financial and accounting expertise of a candidate, including whether an individual qualifies as an “audit committee financial expert.” The nominating committee will consider diversity in identifying nominees for director but has no specific policy or established criteria in this regard. The nominating committee seeks candidates who have a broad range of business experience when considering nominees to the Board of Directors.

Procedures for the Nomination of Directors by Stockholders

The Board of Directors has adopted procedures for the submission of director nominees by stockholders. If a determination is made that an additional candidate is needed for the Board of Directors, the independent members of the Board of Directors will consider candidates submitted by our stockholders. Stockholders can submit the names of qualified candidates for director by writing to our Corporate Secretary at 75 West 3rd Ave., Huntington, West Virginia 25701. The Corporate Secretary must receive a submission not less

Table of Contents

than forty-five (45) days prior to the date of our proxy materials for the preceding year’s annual meeting. The submission must include the following information:

● a statement of the candidate’s business and educational experience;

Stockholder Communications with the Board

A stockholder who wants to communicate with the Board of Directors or with any individual director can write to the Corporate Secretary at 75 West 3rd Ave., Huntington, West Virginia 25701, Attention: Corporate Secretary. The letter should indicate that the author is a stockholder and if shares are not held of record, should include appropriate evidence of stock ownership. Depending on the subject matter, the Secretary will:

At each board meeting, management shall present a summary of all communications received since the last meeting that were not forwarded and make those communications available to the directors.

The Compensation Committee

The compensation committee consisted of directors Joseph L. Williams, Frank Lucente and Dan Mannes. Mr. Lucente and Mr. Mannes were appointed to the committee on December 16, 2020. Each member of the compensation committee is considered “independent” as defined in the NYSE American corporate governance listing standards. The Board of Directors has not adopted a written charter for the Committee. The compensation committee met one time during fiscal year 2021.

The compensation committee is appointed by the Board of Directors to assist the Board in developing compensation philosophy, criteria, goals and policies for our executive officers that reflect our values and strategic objectives. The committee reviews the performance of our executive officers and annually recommends to the full Board the compensation and benefits for our executive officers (including the Chief Executive Officer). The committee administers our equity and long-term incentive plans. The committee establishes the terms of employment and severance agreements/arrangements for executive officers, if applicable. The committee recommends to the full Board the compensation to be paid to our directors and any affiliates for their service on the Board. Finally, the committee establishes annual compensation percentage increases for all employees. Our President and Chief Executive Officer provides recommendations to the compensation committee related to our compensation program. However, our President and Chief Executive Officer does not vote on and is not present for any discussion of his own compensation.

Table of Contents

Energy Services of America CORP ESOA US Equity

ESOA · 10-K · period ended 2021-09-30

ITEM 1.Business

ITEM 1A.Risk Factors

ITEM 1B.Unresolved Staff Comments

ITEM 2.Properties

ITEM 3.Legal Proceedings

ITEM 4.Mine Safety Disclosures

ITEM 5.Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities

ITEM 6. Reserved

ITEM 7.Management’s Discussion and Analysis of Financial Condition and Results of Operations

ITEM 7A. Quantitative and Qualitative Disclosures about Market Risk

ITEM 8.Financial Statements and Supplementary Data

ITEM 9.Changes in and Disagreements with Accountants on Accounting and Financial Disclosure

ITEM 9A.Controls and Procedures

ITEM 9B.Other Information

ITEM 9C.Disclosure Regarding Foreign Jurisdictions that Prevent Inspections.

ITEM 10.Directors, Executive Officers and Corporate Governance

Energy Services of America CORP ESOA US Equity☆

ESOA · 10-K · period ended 2021-09-30

ITEM 1.Business

ITEM 1A.Risk Factors

ITEM 1B.Unresolved Staff Comments

ITEM 2.Properties

ITEM 3.Legal Proceedings

ITEM 4.Mine Safety Disclosures

ITEM 5.Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities

ITEM 6. Reserved

ITEM 7.Management’s Discussion and Analysis of Financial Condition and Results of Operations

ITEM 7A. Quantitative and Qualitative Disclosures about Market Risk

ITEM 8.Financial Statements and Supplementary Data

ITEM 9.Changes in and Disagreements with Accountants on Accounting and Financial Disclosure

ITEM 9A.Controls and Procedures

ITEM 9B.Other Information

ITEM 9C.Disclosure Regarding Foreign Jurisdictions that Prevent Inspections.

ITEM 10.Directors, Executive Officers and Corporate Governance

Energy Services of America CORP ESOA US Equity